The URL can be used to link to this page

Home My WebLink About18-20452 CITY OF ZEPHYRHILLS 5335-8TH STREET' (813)780-0020 20452 BUILDING PERMIT PERMIT INFORMATION LOCATION INFORMATION Permit Number: 20452 Address: 39736 MEADOWOOD LP Permit Type: RE-ROOF ZEPHYRHILLS, FL. Class of Work: ROOF REPLACEMENT Township: Range: Book: Proposed Use: NOT APPLICABLE Lot(s): Block: Section: Square Feet: Subdivision: MEADOWOOD ESTATES Est. Value: Parcel Number: 13-26-21-0140-00000-0130 Improv. Cost: 7,800.00 OWNER INFORMATION Date Issued: 11/14/2018 Name: SOUTHEAST PROPERTY ACQUISITIONS Total Fees: 80.00 Address: PO BOX 9567 Amount Paid: 80.00 TAMPA FL 33674-9567 Date Paid: 11/14/2018 Phone: 813-675-0916 Work Desc: REROOF SHINGLE CONTRACTORS APPLICATION FEES ROOF X REROOF RESIDENTIAL 80.00 G� Q/ DRY IN ROOF IN P Ins ections Required TAPE JOINTS R OF INS FINAL REINSPECTION FEES: (c)With respect to Reinspection fees will comply with Florida Statute 553.80 (2)(c)the local government shall impose a fee of four times the amount of the fee imposed for the initial inspection or first reinspection,whichever is greater,for each such subsequent reinspection. NOTICE: In addition to the requirements of this permit, there maybe additional restrictions applicable to this property that may be found in the public records of this county, and there may be additional permits required from other governmental entities such as water management, state agencies or federal agencies. "Warning to owner: Your failure to record a notice of commencement may result in your paying twice for improvements to your property. If you intend to obtain financing,consult with your lender or an attorney before recording your notice of commencement." Complete Plans, Specifications Must Accompany Application.All work shall be performed in accordance with City Codes and Ordinances. NO OCCUPANCY BEFORE C.O. NO OCCUPANCY BEFORE C.O. n L�& - 4 CONTRACTOR SIGNATURE PERMIT OFFI R PERMIT EXPIRES IN 6 MONTHS WITHOUT APPROVED INSPECTION CALL FOR INSPECTION - 8 HOUR NOTICE REQUIRED PROTECT CARD FROM WEATHER 813-780-0020 City of Zephyrhills Permit Application Fax-813-780-0021 Building Department 50 5} Date Received /l�13-� Phone Contact for Permitting 1.66 Zvi —�5e 1 1 1 1 11_1._I.. ..._... _ _.__._._ .. ...I._. 1._I_.. 4r0wner's Name Owner Phone Number 3—675 01111 Yy/U�k�9�/1S Owner's Address _c M L Owner Phone Number Fee Simple Titleholder Name PC) Owner Phone Number 11 Fee Simple Titleholder^✓Address 1' JOB ADDRESS req s z PhN tir 115 �fY(' LOT# 113 /►I� SUBDIVISION � ! G 'I PARCEL ID# O-Z —V I�I -DDOI � 3 v (OBTAINED FROM PROPERTY TAX NOTICE) WORK PROPOSED B NEW CONSTR� ADDIALT = SIGN = DEMOLISH INSTALL REPAIR PROPOSED USE = SFR = COMM = OTHER TYPE OF CONSTRUCTION = BLOCK (1 = FRAME C = STEEL i = 117 DESCRIPTION OF WORK IGC�OT ��15�IY1C 5 rr_4VrC. BUILDING SIZE j SO FOOTAGE /u0� HEIGHT 1 1 1 1 1 1 1 1 1 1 1 I l t l l A 1 1 1 1 1 A =BUILDING $7S io VALUATION OF TOTAL CONSTRUCTION =ELECTRICAL $ AMP SERVICE = PROGRESS ENERGY = W.R.E.C. =PLUMBING $ =MECHANICAL $ VALUATION OF MECHANICAL INSTALLATION =GAS = ROOFING SPECIALTY = OTHER FINISHED FLOOR ELEVATIONS I FLOOD ZONE AREA =YES NO BUILDER OMPANY gtJi./Y SIGNATURE L EGISTERED Y/ N FEE CURREt` Y J N I"� 1, O DV Address / SI License# lJw 13300 Sri ELECTRICIAN COMPANY SIGNATURE F REGISTERED Y/ N FEE CURREN I Y/N Address I License# PLUMBER COMPANY SIGNATURE REGISTERED Y/ N FEE CURREt I Y/N Address License# MECHANICAL COMPANY SIGNATURE REGISTERED I Y/ N FEE CURREN I Y/N Address License# OTHER COMPANY SIGNATURE REGISTERED I Y/ N FEE CURREN I Y/N Address License# IIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIItlllllllllllllllllllllllllllllll RESIDENTIAL Attach(2)Plot Plans;(2)sets of Building Plans;(1)set of Energy Forms;R-O-W Permit for new construction, Minimum ten(10)working days after submittal dale. Required onsite,Construction Plans,Stonnwater Plans w/Silt Fence installed, Sanitary Facilities&1 dumpster;Site Work Permit for subdivisions/large projects COMMERCIAL Attach(2)complete sets of Building Plans plus a Life Safety Page;(1)set of Energy Forms.R-O-W Permit for new construction. Minimum ten(10)working days after submittal date. Required onsite,Construction Plans,Stonnwater Plans w/Sill Fence installed, Sanitary Facilities&1 dumpster.Site Work Permit for all new projects.All commercial requirements must meet compliance SIGN PERMIT Attach(2)sets of Engineered Plans. ""PROPERTY SURVEY required for all NEW construction. Directions: Fill out application completely. Owner&Contractor sign back of application,notarized If over$2500,a Notice of Commencement is required. (A/C upgrades over$7500) Agent(far the contractor)or Power of Attorney(for the owner)would be someone with notarized letter from owner authorizing same OVER THE COUNTER PERMITTING (copy of contract required) Reroofs if shingles Sewers Service Upgrades A/C Fences(Plot/Survey/Footage) Driveways-Not over Counter if on public roadways..needs ROW NOTICE OF DEED RESTRICTIONS T11e undersigned understands Inal tNs perT^'frppns,blkrle�etd�e3w , Y vetch may De more resmanre than County regulalons. The undersigned assl lit aPPllcable deed restrictions er has Iwcd f UNLICENSED CONTRACTORS AND CONTRACTOR RESPONSIBILITIES' It the own ° �ag11 a COnIfaGors to undertake work.they may be required to be licensed m accordance w.tncited fan atmisdemeeanor ons II the ron Contractor is not licensed as r law, for xer under Cgrinle by bolt the avner and contractor may si recitnrements May phy to, slate law If the avner or conned Contractor era trntertan as tO anal I�nsr°Gn' ng Section at 717. �-0 intended � Ices' 8t7- work,they are advised to contact the Pasco County Bu,ldtng Inspedio^O 80D9 Furthermore, d the owner has hired a contractor or contractors.he Is a ble i to have the cantraaorts)sign contorts of the'contractor Block'of Ihrs application for which Ihey vvtll be fesPOns'�I d 1 ypermu ttng pnwegein p�' contractor,that may be an Indication that he Is not property licensed and IS not en asoO Count' Y FEES The unders ned thatTransportation I+mDaclAFees and RecoursTILITlES e Recovery Fees may DPN 10 nCT AND RESOURCE R�ounhton of nov nonce nub 89.07 e of and use in existing buildings.Or expansion of existing bmld,ngs.as specified m Pasco dl,c.Ml be tdenhAed at the hme 90 07. as amended The unders ned also understands.that such fees as may De b-paid of Pemutbng 1t Is further understood that Transportation Impact Fees and Reso+uce R ool e a certificatevery toff occupa r rior to rewlvnng a"ccmlficate of-OLiPancy'Or final M,.e,rerease If the protect does nolf Pasco Cary WatedSe vex Ir D8q final Dowver release the fees must be paid poor to permit issuance Furthermore• pasco County ordinartres Ices are due.IheY mrfst be paid prior to permit Issuance m accordance N+th appI,C41 f work is S2.SW 00 or CONSTRUCTION LIEN LAZY(Chapter 713,Florldta Statutes,ras,mooned) If valuattru of Lien Law—mO f1pfe.I cwws Certify that 1, the app!tcanl have been provided twin a copy Of the 'Florida Co^ a rs If Irre applicant IS Sornepft Protection Guide'prepared by the Ftonda Department of Agriculture and Cd silent and promise m good faith tO other than fhe'owner'"I certify that I have obtained a copy of the above descin deliver 1110 the-owner-prior to commencement. cation is accurate and that an work CON TRACTOR'SIOWNER'S AFFIDAVIT. 1 cent that all the information in This aPpl wltl be done to compliance vwlh all applicable laws regulating construction,zoning a^d land devefcpmenl. Application is hereby made to obtain a Permit t pdo work and rnstallahon as indicated I tenth that no work or lawaUabcn rids Commenced prior Id Issuance Of a Permit and that all work will be performed IO rpeet standards of unall taws regula!so construction.County and City codes,zoning regulabons,and land development regrrlatiors in the Junsd.cticn. I aso Certrty that I understand that the regulations of other government agencies may apply to me Intended wGnc,and Itcat rt is My responsibility to identity wwtmt actions 1 must take to be in compliance 5urh age^�inanude but one rat aDy the Department of Environmental Protection-Cypress Bayteads.Wetland Areas arsd Enwonmenta Lands.Wtilerhvasl water Treatment. Bads. Wetland Areas. Altering Southwest Florida %water Management Disle4.V%eUs, Cypress Watercourses. A,mry Corps of Engineers-Seawalls.Dodos,Navigable Water%%70- , Department of Health&Rehabilitative ServixyEnvironmenlal Health Unit'Wers• Was.ewa:er Trealmclt Septic Tanks. US Environmental Protection Agency-Asbestos abatement Federal Aviation AtnhantyRtmwrruys. understand that the following reslnctions apply to the use of fin: Use of fill is not allowed in Flood Zone V unless expressly permitted. If the fill material is to be used in Flood Zone'A',it B understood that a drainage plan adl-essing a 'compensating volume'w,q be submitted at lime of pennttbng wfuch Is prepared by a professional engneer licensed by the State of Florida. If the fill material is to be used in Flood Zone A-In cornecgon wwi.71 a pemnitted building using stem ww� construction.I certify that fill will be used only to fill the area writhin the stem wall- if fill material is to be used in any area. I certify that use or such rill will not adversely a9eci a.acent properties. If use of fill is found to adversely affect adjacent properties,the Omer may be aced for v:cIat:rrg the cond•bons of the building permit Issued under the arached permit application,for lots less than one(1) acre wruch are elevated by fill,an engineered drainage plan is required. If I am the AGENT FOR THE OWNER.I promise in good faith to inform the owner of the permitting conditions set forth in this affidavit poor to commencing construction. I understand that a separate permit may be required for electrical vv9rk, plumbing,signs.wells.pools,au conditioning.gas,or other Installations not specifically included in the apPtrcatton. A permit issued shall be convirued to be a license to proceed with the wvork and not as authority to violate.Cancel.otter,or set aside arty provisions of the technical tales.nor shall issuance of a permit prevent the Building OMcial from lherealer regtnnng a correction of errors to plans,construction or violations of any codes. Every permit issued shall bec;me erw•a'd unless the work authorized by such permit is commenced wwlnrn six months of permit Issuance,or if work au:hereed by i the permit is suspended or abandoned for a period of six(6)months after the time the work is commenced A.•n ex:ensten may be requested,to writing•from the Building Official for a period not to exceed ninety(90)days and wy demonstrate ) Justifiable cause for fie extension. If work ceases for ninety(90)consecutive days,the Job is considered abandoned. WARNING TO OWNER: YOUR FAILURE TO RECORD A NOTICE OF COMMENCEMENT MAY RESULT IN YOUR PAYING TWICE FOR IMPROVEMENTS TO YOUR PROPERTY. IF YOU INTEND TO OBTAIN FINANCING,CONSULT WITH YOUR LENDER OR AN ATTORNEY BEFORE RECORDING YOUR NO11 E OF COMMENCEMENT FLURID/..A)RAT(r 5 1If 03) OWNER OR AGENT CR-C TOR j St.bsaom and t.an 13 la 011TWOj before die ilea q4Yhd ware personaar known to the or"ubz we Proauud 'I-, per$Ms. lrxv. a iT�7r tustuwe br:•Cuced n benCrU'+tn Notkry ru4C Corrml'utn No I��111111YY Nerary Pwc conwnllwn No F ►amine Of radwy r1PW pnmrd or Ms L4Urt:� 1L• roes name or rotary gyed WIN oft. }a! h COS.mission c FFyrd5I5 - EXPIRES Ocicver 19 2019 WC _^in nt 5t .r„ ..-rr Scanned with CarnScanner R rSales Rep Diaz OOF Dale 11/12/2618 Time 8:23am Rene THE ROOF-G CUSTQNIERFINFORIUTATION Excellence Through Experience! Name ~ r SPIN Real Estate 0:844-877-6639* 5009 N Central Ave Tampa Fl F:966-262-7663 Job Address 39736 Meadowood Loop Zephyrhills F1 1 1613 Marshwood Dr seffner,F1 33584 81 M75-0916 LIQ CCC1330839 Email krystle.g6rdon@spi'ncompanies.com !iREdFICATIONS _-60WP11 POSP.N. K' Reroof X New ,�Ex�ting'R Shingle Roof . )<Pull permits required,schedule inspections -UhAi NT '' needed and furnish results to owner. Tamko Heritagd 3.0 Rhino Synthetic)< )<Tear off existing roof down to decking Peak P+S )<Re-nail decking to code and replace any Midstate P+S rotten wood,if necessary* Lomanco RV >( Other Type: )< Install selected roofing material in accordance Dryer Vents )< Notes- with Florida Building Codes and complete with Off Ridge Synthetic all I applicable flash in.gs .. . Pipe Boots >(Remove all trash and debris from job site Other- -LdW SLOPE-SING E'P(yj IM '---*-"-"'- GAF Everguard TPO NA , Install,30 year Tamko Heritage with synthetic GAF Liberty SA Base and Cap underlayment. Five year labor warranty. Certainteed FIJ ntastlic.Base and Cap Notes- Plaid-,I SV'AjFW Ri 3"&' k6kikfi OF-E 1 "[$77800.00 �T w,g `Important Note:Please not any rotten decking beyond 2 sheets will be billed at $65.00 per sheet and $5.50 per linear foot of framing or fascia. BILLING.TER With paymentto be made as follows: $3,900.00 due up front with signed proposal and remaining $3,900.00 balance due immediately diately upon completion." Additional Terms "The above prices and scope of work are satisfactory and Roof X,Inc.Is hereby authorized to do the work as set forth and payments will be made as outlined above viv,,w.roof xi ncfl.corn R-00F."'X TERMS AND CONDITIONS I.THE UNDERSIGNED,HAVE READ AND UNDERSTAND ALL STATEMENTS AND CONDITIONS OF THE ROOF REPLACEMENT CONTRACTAND AGREE THAT ALL DETAILS ARE ACCEPTABLE AND SATISFACTORY.I FURTHER UNDERSTAND THAT THIS CONTRACT CONSTITUTES THE ENTIRE AGREEMENT BETWEEN THE PARTIES AND THAT ANY FURTHER CHANGES OR ALTERATIONS TO THIS CONTRACT MUST BE MADE IN WRITING AND AGREED TO BY BOTH PARTIES.EACH PARTY REPRESENTS AND WARRANTS TO THE OTHER THAT IT HAS THE FULL POWER AND AUTHORITY TO ENTER INTO THE CONTRACT AND THAT IT IS BINDING AND ENFORCEABLE IN ACCORDANCE WiTH ITS TERMS. 1.ACCEPTANCE OF TERMS:Owner,hereby agree to retain Company's service for a full roof replacement on the terms and conditions stated herein.I further authorize and grant full access to the property for the purpose of staging and completing all agreed upon work. 2.COMMENCEMENT OF WORK: Work shall commence at Company's discretion.Company shall not be liable for delay in,or failure to perform due to labor controversies,strikes,fire,weather,acts of God,war,governmental actions,inability to obtain materials from usual sources,delays caused by,and/or as a direct result of Owner's Insurance company or other circumstances not listed which are beyond the control of Company. 3.INSURANCE:Roof X Inc.("Contractor')shall cant'worker's compensation,automobile liability,commercial general liability and such other insurance as required by law. Contractor will furnish a Certificate of Insurance,evidencing the types and amounts of its coverages,upon request. Customer shall purchase and maintain builder's risk and property insurance,covering fire,storm, vandalism,theft and other perils,including the labor,material and equipment furnished by Contractor,until the job is completed and accepted and Contractor's equipment is removed from the premises 4.CHANGES IN THE WORK AND EXTRA WORK: Customer shall be entitled to order changes in the work and the total contract price shall be adjusted accordingly. Any penetrations through the roofing to be installed by Contractor not shown on the plans provided to Contractor prior to submittal of this proposal shall be considered an order for extra work. Any change in specifications or construction necessary to conform to existing or future building codes,zoning laws,or regulations of the inspecting Public Authorities shall be considered additional work to be billed as an extra charge on a time and material basis. Unless otherwise noted in this agreement,the price quoted does not include removing or replacing fascia,trim,sheathing,rafters,structural members,siding, masonry,vents;roofing,caulking,metal-edging or flashing of any type. If,during the course of work,It should become apparent that any such portions of the structure should be repaired or replaced,Customer may authorize Contractor to do such additional work for an extra charge. S.RIGHT TO STOP WORK:The failure of Customer to make proper payment to Contractor when due shall entitle Contractor,at its discretion,to suspend all work and shipments,including furnishing warranty,until full payment is made or terminate this contract. The contract sum to be paid Contractor shall be increased by the amount of Contractor's reasonable costs of shut-down delay and start-up. Should work be stopped for more than 30 days by order of any agency of government,the Contractor may terminate this contract and collect for all work completed plus a reasonable profit. 6.BACK CHARGES: No back charges or claims for payment of services rendered or materials and equipment furnished by Customer to Contractor shall be valid unless previously authorized in writing by Contractor and unless written notice is given to Contractor within ten(10)days of the event,act or omission which is the basis of the back charge. 7.CONSTRUCTION DEBRIS:Upon completion of work,Company will make a reasonable effort to remove debris from the property including but not limited to general clean-up of construction-related debris and a magnetic sweep of the eave line and walkways surrounding project area. Company cannot guarantee the removal of all nails and/or debris.Company shall not be liable for any AMq- resulting damages. 8.LANDSCAPING:While Company shall make reasonable efforts to safeguard the lawn and/or shrubbery,it is the sole responsibility of Owner to remove any and all lawn ornaments,exterior furniture and valuables.Company cannot guarantee the safekeeping of these hems nor shall Company assume liability for damage: 9.TIMELY PAYMENT:Owner's responsibility to ensure prompt payment to Roof X Inc.and not to exceed 3 business days from receipt of invoice.Customer will accrue a 1%late charge fee per day. 10.FORCE MAJEURE:Company shall not be liable for any natural and/or unavoidable catastrophes that interrupt the expected course of events and restricts Company from fulfilling its obligations herein,such as,but not limited to,excessive wind,hail,ice,rain, extreme weather conditions,fire,war,governmental actions or other acts of God. 11.LABOR WARRANTY:Company shall provide to Owner a two(2)year(unless otherwise sated in notes section),non-transferrable warranty on labor.Company is not responsible for any damage below the roof due to,but not limited to,leaks,cracks,fissures,etc: caused by excessive wind.ice,hail,snow or any other act of God during the period of warranty. In the event of an extreme weather condition or act of God which warrants an insurance claim,Labor Warranty shall be void. 12.WARRANTY EXCLUSIONS:Company shall have no liability for damages from fires,windstorms or other hazards as is normally covered by Homeowner's Insurance or Builders Risk Insurance unless specific,written agreement is made prior to commencement. This Contract,and any warranty provided shall not be assigned or transferred by either party,except by written instrument and signed by both parties 13.MANUFACTURER WARRANTY ON MATERIALS: All materials used are subject to Manufacturer's Limited Shingle Warranty.Any defect of materials is covered,and subject to,the manufacturer's warranty specifications;this shall void Company's Labor Warranty. 14.PRE-EXISTING MATERIALS:Repair of deteriorated decking,"waves"in'decking,fascia boards,roof jacks,ventilators,flashing, chimneys,gutters or other such materials(unless otherwise expressly stated in the Contract)are not included.Should Owner elect to repair any and/or ail of these pre-existing materials. Owner shall be charged for both materials and labor.Company shall be liable neither for the replacement of,nor for any damages arising from Owner's election to retain these pre-existing materials. 15.PRE-EXISTING CONDITIONS:Company shall not be responsible or liable for issues due to improper ventilation,deteriorated decking, "waves"in decking, appearance of roof due to irregularities in underlying roofing system or other pre-existing,structural defects. 16.SHINGLE COLOR CHANGE:Should a shingle color change be requested within forty-eight(48)hours of the mutually agreed upon Installation date,a$17.00 express shipping fee shall be charged by Company to Owner.This fee MUST be paid on date of installation. 17.MINIMUM CONTRACT: Company reserves the right to terminate any Contract if Contract Price does not exceed$4,999.99. 18.SEVERABILIiY: If any provision of this Contact is held by a court of competent jurisdiction to be contrary to law,then the remaining provisions of this agreement or the application of such provision to persons or circumstances other than those as to which it is invalid or unenforceable shall not be affected thereby,and each such provision of this Contract shall be valid and enforceable to the extent granted by law. 29.BINDING ARBITRATION:If a dispute arises from or relates to this Contract or the breach thereof,and if the dispute cannot be settled through direct discussions, the parties agree to endeavor first to settle the dispute by mediation administered by the American Arbitration Association under Its Construction Industry Mediation Procedures before resorting to arbitration.The parties further agree RICK UeAr That any unresolved controversy or claim arising out of or relating to this Contract,or breach thereof,shall be settled by arbitration administered by the American Arbitration Association in accordance with its Construction Industry Arbitration Rules and judgment on the award rendered by the arbitrators may be entered in any court having jurisdiction thereof.The statute of limitations on all disputes which arise from or relate to this Contract or a breach thereof shall.be one(1)year,from the date of signing Roof Replacement Contract.Claims shall be heard by a panel of three(3)arbitrators.The mediator shall not he empanelled as an arbitrator. The place of arbitration shall be Atlanta.Georgia.The arbitration shall he governed by the laws of the State of Georgia.All deposits, fees and expenses of the mediation and/or arbitration,including required traveling and other expenses or charges of the mediator and/or arbitrator,shall be home by the initiating party. Depositions shall be limited to a maximum of twenty-five(25)per party and shall be held within one hundred eighty(180)clays of the making of a request.Additional depositions may be scheduled only with the permission of the arbitrators,and for good cause shown.Each deposition shall be limited to a maximum of 8 hours duration. Any dispute regarding,discovery or the relevance or scope..thereof,shall be determined by the arbitrators,which determination shall be conclusive.The arbitrators will have no authority to award punitive,consequential or other damages not measured by the prevailing party's actual damages,except as may be required by statute.In no event shall an award in arbitration exceed the amount of the Roof Replacement Contract.Any award in an arbitration initiated under this clause shall be limited to monetary damages and shall include no injunction or direction to any party other than.the direction to pay a monetary amount.The award shall not include pre or post-judgment interest.The award of,the arbitrators.shall.he accompanied by a•reasoned opinion.Notwithstanding any language to the contrary in the contract documents. the parties hereby agree that the Underlying Award may be appealed pursuant to the F AAA's Optional Appellate Arbitration Rules("Appellate Rules");that the Underlying Award rendered by the arbitrator(s)shall, at a minimum,be a reasoned award;and that the Underlying Award shall not be considered final until after the time for filing the notice of appeal pursuant to the Appellate Rules has expired.Appeals must he initiated within thirty(30)days of receipt of an Underlying Award,as defined by Rule A-3 of the.Appellate Rules,by filing a Notice of Appeal with any AAA office.Following the appeal process the decision rendered by the appeal tribunal may be entered in any court having jurisdiction thereof.Except as required by law, neither party nor an arbitrator may disclose the existence,content or results of any arbitration hereunder without the written consent of both parties.Should either party disclose the existence,content or results of any arbitration hereunder.that party shalt forfeit and-and all damages awarded as a result of arbitration., 20.DAMAGES:TO THE EXTENT PERMITTED BY LAW,IN NO EVENT SHALL COMPANY,ITS OFFICERS,DIRECTORS,.SHAREHOLDERS, REPRESENTATIVE,EMPLOYEES,ATTORNEYS,AFFILIATED ENTITIES OR INSURERS BE LIABLE TO OWNER FOR ANY INCIDENTAL,INDIRECT, PUNITIVE,SPECIAL OR CONS EQUENTIAL.DAMAGES ARISING OUT OF OR RELATED TO THE PERFORMANCE.NONPERFORMANCE OR, TERMINATION OF CONTRACT. Guru Signature Customer Signature Rene -Diaz Gj ROOF _.-.tHE ROOF Gt�RuSrd__. . w } You Roofing Need is Our Prior4l"w O: 1 (844)877-6636 F: 1 (866)262-7663 4906 Presidential St,Seffner FL 33584 Letter of Authorization To whom it may concern: Let this letter stand as proof that Dakota Frady and Anthony Bryant hereby are authorized to pull roof permits on behalf of Roof X Inc located at 4-906 Presidential St Seffner,F133584 until permission is revoked by an officer of Roof X inc in writing.Any questions I can be reached at 813-629-0581. Sincerely, Rene Diaz oof c i v ' LAUREN K SOLANO •- MY COMMISSION 0 FF928815 EXPIRES October 19.2019 FkxdiallotaryServitssom • lIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIIillllllllllllll{IIII{IIIII 2018211472 NOTICE OF COMMENCEMENT Rept.:2014227 Rec: 10.00 DS: 0.00 IT: 0.00 12/18/2018 K. R. M. , Dpt,y Clerk Permit No. Tax Folio No.l n-t=QCn Q-plZM THE UNDERSIGNED hereby gives notice that improvements will be made to certain real property,and in accordance with Section 713.13 of the Florida Statutes,the following information is provided in this NOTICE OF COMMENCEMENT. ,.a v N� I.Description of property(legal descrl lion): o a a)Street(Job)Address:3q l 0 t Q.00 I o IS FL 3 y a- a u, 2.Geneml description of improvements: T 0D'o X N ixt '17ry r- m 3.Owner Information n)Name and address• 'I— •Q rt 17 m T' b)Name and address of fee simple titleholder(if otheethan owner) N/A "j'GtT rTc �� t o c)Interest in property.N/A 4.Contractor Information 3 0 a)Name and address- f lno-g -Tp( M-3 w anzl,aoyd Or e�- FL 3-3.5(3' -o b)Telephone No.: ,��3-e Lei-oSB) Fax No.(Opt.) N/A 0 m 5.Surety Information c X a)Name and address: N/A -.,P. b)Amount of Bond: N/A co c)Telephone No.: N!A Fax No.(Opt.) N/A 'r 6.Lender o a)Name and address: N/A r Phone No. tN/A x 7.Identity of person within the State of Florida designated by owner upon whom notices or other documents may be served: a)Name and address: N/A b)Telephone No.: N/A Fax No.(Opt.) N/A 8.In addition to himself,owner designates'the following person to receive a copy of the Lienor's Notice as provided in Section 713.13(1)(b),Florida Statutes: a)Name and address: N/A b)Telephone No.: N/A Fax No.(Opt.) N/A 9.Expiration date of Notice of Commencement(the expiration date is one year from the date of recording unless a different date is specified): One year from the date of recording WARNING TO OWNER: ANY PAYMENTS MADE BY THE OWNER AFTER THE EXPIRATION OF THE NOTICE OF COMMENCEMENT ARE CONSIDERED IMPROPER PAYMENTS UNDER CHAPTER 713,PART I,SECTION 713.13, FLORIDA STATUTES,AND CAN RESULT IN YOUR PAYING TWICE FOR IMPROVEMENTS TO YOUR PROPERTY. A NOTICE OF COMMENCEMENT MUST BE RECORDED AND POSTED ON THE JOB SITE BEFORE THE FIRST INSPECTION. IF YOU INTEND TO OBTAIN FINANCING,CONSULT YOUR LENDER OR AN ATTOILNEY BEFORE COMMENCING WORK OR RECORDING YOUR NOTICE OF COMMENCEMENT. STATE OF FLORIDA /, 1" _t, COUNTY OF 10. IA '` / try Signature caner or O� er s Authorized Officer/Director/Partner/Manager Print Name ' The foregoing instrument was acknowledged before me this ,( day ofYv00e..rfnk>� ,20_L by F1,4V ) LL�l PLC 0.S as C-k"roj 1�Lf ✓l Q_ -� (type of authority,e.g.officer,trustee, attorney in fact)for lac gta rVT7A io 1 Ll_ _(name of party`o/n behalf ofwhom instrument was executed). Personally Knowr'�OR Produced Identification_ Notary Signature Type of Identification Produced Name(print) \<nl_ 5 Cn L-.,4,CU-,:h u itacm� Ij Verification pursuant to Section 92.525,Florida Statutes.Under penalties of perjury,)declare that I have read the foregoing and that the facts stated in it are true to the best of my knowledge and belief. //�(� FOR\WOCmd= a "� Signature of Natural Person Signing(in line t!10.)Above KRYSTLE GORDON :State of Florida-Notary Public Commission 6 GG 202090 My Commission Expires April 01, 2022 , • p » . � ` STATE[)F . ��UNTY OFFASC�� THIS\G� 1ERT|FY FLORIDA, THE FOREGOING\SA TRUE AND CORRECT COPY OF THE DOCUMENT DN FILE OROF PUBLIC RECORD |N THIS OFFICE UWTN SSMYHANDA OFFICIAL ZS�Al-TH|S in God-We Tntst (KVJ DAY OF 0 ,J 2 PO C/ PAULA TROLLER DEPUTY CLERK 1887 BY �3 00 00 Ua City of Zephyrhills 1h St 2 5335 8 .. ..... Zephyrhills FL 33542 (813)780-0020 ROOFING INSPECTION AFFIDAVIT Permit No.: licensed under Chapter 468,Florida statutes as a(n): Contractor_Engineer—Architect—Building Inspector LicenseNo. Q On or about Z did personally inspect Check: Roof Deck NailingL Z. Dryy.in personally and Drip edge Check which was used: 30#felt- Peel and Stick- ---Other-(List 1/0 -t-; At the following -W73 qL 1 AL address 1� 1 & qo ! � Ajhilrs- Based upon that examination,I have determined the installation was done according to the Hurricane Mitigation Retro nua ed o n 553.844,Florida Statutes). ti Signature: STATE OF FLORIDA COUNTY OF PASCO Sworn to andstibscribed bef" is ay BY: Notary Public State of Florida �D is v Ya` L A WoAU J �N K S OLA MycoMMisStoN 4 F 92881 5 EXPIRES October 19.2019 Igp7) Fbiidallotary$arvice.c , tz!