HomeMy WebLinkAbout20-571 0
Wdfl City pyrhills- Ci of Ze h
F Ufllfl
5335 Eighth Street PERMIT NUMBER
�//
Zephyrhills, FL 33542 BG R-000671-2020
Phone: (813)780-0020
Fax: (813)780-0021 Issue Date: 08/14/2020
Permit Type: Building General (Residential)
Property Number Street Address
35 25 210120 00000 1390 7918 Merchantville Circle
Owner Information Permit Information - Contractor Information
Name: JAMES&LYNDSEY GRIFFIN Permit Type:Building General(Residential) Contractor: RJ KIELTY PLUMBING,
Class of Work:HVAC Changeout HEATING &COOLING
Address: 7918 Merchantville Cir Building Valuation:$0.00
ZEPHYRHILLS,FL 33542 Electrical Valuation:$0.00
Phone: (276)728-8243 Mechanical Valuation:$8,893.00 ��7 ��
Plumbing Valuation:$0.00
Total Valuation:$8,893.00
Total Fees:$84.46
Amount Paid:$84.46
Date Paid:8/14/2020 10:17:18AM
Project Description
A/C CHANGE OUT 3 TON
Application Fees
Mechanical Permit Fee $84.46
REINSPECTION FEES: (c)With respect to Reinspection fees will comply with Florida Statute 553.80(2)(c)the
local government shall impose a fee of four times the amount of the fee imposed for the initial inspection or
first reinspection,whichever is greater,for each subsequent reinspection.
Notice: In addition to the requirements of this permit, there may be additional restrictions applicable to this property that
may be found in the public records of this county, and there may be additional permit required from other governmental
entities such as water management, state agencies or federal agencies.
"Warning to owner:Your failure to record a notice of commencement may result in your paying twice for
improvements to your property. If you intend to obtain financing,consult with your lender or an attorney
before recording your notice of commencement."
Complete Plans,Specifications add fee Must Accompany Application.All work shall be performed in
accordance with City Codes and Ordinances. NO OCCUPANCY BEFORE C.O.
NO OCCUPANCY BEFORE C.O.
CONTRA TO SIGNATURE PE IT OFFICE
PERMIT EXPIRES IN 6 M NTHS WITHOUT APPROVED INSPECTION
CALL FOR INSPECTION - 8 HOUR NOTICE REQUIRED
PROTECT CARD FROM WEATHER
813-780-UD2U City of Zephyrhills Permit Application Fax-813-780-DD21
Building Department
Date Received Permitting 13 �{3 3 _ 3 S S'
Phone Contact for Per 7
wait a aa! aataa
Owner's Name DES �R�FFi�r Owner Phone Number
Owner's Address 79/8 / F,?,9H A17 k.,#0 GaCA Owner Phone Number
Fee Simple Titleholder Name Owner Phone Number
Fee Simple Titleholder Address p
JOB ADDRESS 79/,p /0JE,EL440-1Td,"11E �/2C�£ LOT# �3
SUBDIVISION C-RESTY Eta /Tr�ls PARCEL ID# W Z r-Z•f'G/"'166000 - 13 90
(OBTAINED FROM PROPERTY TAX NOTICE)
WORK PROPOSED NEW
CONSTR ALL REPAIR e SIGN = = DEMOLISH
INSPROPOSED USE = SFR Q COMM = OTHER
TYPE OF CONSTRUCTION = BLOCK Q FRAME = STEEL =
DESCRIPTION OF WORK C fZEsiDE/I�T�fj4 G/tA/1/G� maT
BUILDING SIZE I SQ FOOTAGE HEIGHT
.-CLYLCL LLL L'Lii'LLLL L-!'LL"Li CLlC"L''lLCL-LCCL"Liiiii"L"ii"C!"'LZ iLZ i't i"L LI L�LLLL-L"C!-1
=BUILDING $ VALUATION OF TOTAL CONSTRUCTION
=ELECTRICAL $ AMP SERVICE = PROGRESS ENERGY 0 W.R.E.C.
=PLUMBING $
=MECHANICAL Is
GrY3 VALUATION OF MECHANICAL INSTALLATION
=GAS = 7ROOFING Q SPECIALTY Q OTHER
FINISHED FLOOR ELEVATIONS I FLOOD ZONE AREA =YES NO
BUILDER COMPANY
SIGNATURE REGISTERED Y/N FEE CURREN Y/N
Address I License#
ELECTRICIAN COMPANY
SIGNATURE REGISTERED Y/N FEE CURREN LZI N
Address License#
PLUMBER COMPANY
SIGNATURE REGISTERED Y/N FEE CURREN L11 N
Address License#
MECHANICAL COMPANY R-1-14161-TY I/ &giTIN6� '�L ewu S
SIGNATURE REGISTERED Y/N, FEE CURREN I Y/N
Address �97�dVASSIfeNEtS�Tt.S /ft/E �P���f. License# I cA'r-
OTHER COMPANY
SIGNATURE REGISTERED Y/N FEE CURREN I Y/N
Address License#
a a a a a a a a i a i i x a a
RESIDENTIAL Attach(2)Plot Plans;(2)sets of Building Plans;(1)set of Energy Forms;R-O-W Permit for new construction,
Minimum ten(10)working days after submittal date.Required onsite,Construction Plans,Stormwater Plans w/Silt Fence installed,
Sanitary Facilities&1 dumpster;Site Work Permit for subdivisions/large projects
COMMERCIAL Attach(2)complete sets of Building Plans plus a Life Safety Page;(1)set of Energy Forms.R-O-W Permit for new construction.
Minimum ten(10)working days after submittal date.Required onsite,Construction Plans,Stormwater Plans w/Silt Fence installed,
Sanitary Facilities&1 dumpster.Site Work Permit for all new projects.All commercial requirements must meet compliance
SIGN PERMIT Attach(2)sets of Engineered Plans.
****PROPERTY SURVEY required for all NEW construction.
Directions:
Fill out application completely.
Owner&Contractor sign back of application,notarized
If over$2500,a Notice of Commencement is required.(A/C upgrades over$750D)
•• Agent(for the contractor)or Power of Attorney(for the owner)would be someone with notarized letter from owner authorizing same
OVER THE COUNTER PERMITTING (copy of contract required)
Reroofs if shingles Sewers Service Upgrades A/C Fences(Plot/Survey/Footage)
Driveways-Not over Counter if on public roadways..needs ROW
813-760-0020 City of Zephyrhills Permit Application Fax-813-78U-0021
Building Department
NOTICE,OF DEED RESTRICTIONS:The undersigned understands that this permit may be subject to"deed"restrictions"which may be more restrictive
than County regulations.The undersigned assumes responsibility for compliance with any applicable deed restrictions.
UNLICENSED CONTRACTORS AND CONTRACTOR RESPONSIBILITIES:If the owner has hired a contractor or contractors to undertake work,they
may be required to be licensed in accordance with state and local regulations.If the contractor is not licensed as required by law,both the owner and
contractor may be cited for a misdemeanor violation under state law.If the owner or intended contractor are uncertain as to what licensing requirements
may apply for the intended work,they are advised to contact the Pasco County Building Inspection Division—Licensing Section at 727-847-8009.
Furthermore,if the owner has hired a contractor or contractors,he is advised to have the contractor(s)sign portions of the"contractor Block"of this
application for which they will be responsible.If you,as the owner sign as the contractor,that may be an indication that he is not properly licensed and is
not entitled to permitting privileges in Pasco County.
TRANSPORTATION IMPACT/UTILITIES IMPACT AND RESOURCE RECOVERY FEES:The undersigned understands
that Transportation Impact Fees and Recourse Recovery Fees may apply to the construction of new buildings,change of use in existing buildings,or
expansion of existing buildings,as specified in Pasco County Ordinance number 89-07 and 90-07,as amended.The undersigned also understands,that
such fees,as may be due,will be identified at the time of permitting.It is further understood that Transportation Impact Fees and Resource Recovery
Fees must be paid prior to receiving a"certificate of occupancy"or final power release.If the project does not involve a certificate of occupancy or final
power release,the fees must be paid prior to permit issuance.Furthermore;if Pasco County Water/Sewer Impact fees are due,they must be paid prior
to permit issuance in accordance with applicable Pasco County ordinances.
CONSTRUCTION LIEN LAW(Chapter 713,Florida Statutes,as amended):If valuation of work is$2,600.00 or more,I certify that I,the applicant,
have been provided with a copy of the"Florida Construction Lien Law—Homeowner's Protection Guide"prepared by the Florida Department of
Agriculture and Consumer Affairs.If the applicant is someone other than the"owner",I certify that I have obtained a copy of the above described
document and promise in good faith to deliver it to the"owner"prior to commencement.
CONTRACTOR'S/OWNER'S AFFIDAVIT:I certify that all the information in this application is accurate and that all work will be done in compliance with
all applicable laws regulating construction,zoning and land development.Application is hereby made to obtain a permit to do work and installation as
indicated.I certify that no work or installation has commenced prior to issuance of a permit and that all work will be performed to meet standards of all
laws regulating construction,County and City codes,zoning regulations,and land development regulations in the jurisdiction.I also certify that I
understand that the regulations of other government agencies may apply to the intended work,and that it is my responsibility to identify what actions I
must take to be in compliance.Such agencies include but are not limited to:
- Department of Environmental Protection-Cypress Bayheads, Wetland Areas and Environmentally Sensitive
Lands,Water/WastewaterTreatment.
- Southwest Florida Water Management District-Wells, Cypress Bayheads, Wetland Areas, Altering
Watercourses.
- Army Corps.of Engineers-Seawalls,Docks,Navigable Waterways.
- Department of Health & Rehabilitative Services/Environmental Health Unit-Wells, Wastewater Treatment,
Septic Tanks.
- US Environmental Protection Agency-Asbestos abatement.
- Federal Aviation Authority-Runways.
I understand that the following restrictions apply to the use of fill:
- Use of fill is not allowed in Flood Zone W"unless expressly permitted.
- If the fill material is to be used in Flood Zone "A", it is understood that a drainage plan addressing a
"compensating volume"will be submitted at time of permitting which is prepared by a professional engineer
licensed by the State of Florida.
- If the fill material is to be used in Flood Zone "A" in connection with a permitted building using stem wall
construction, I certify that fill will be used only to fill the area within the stem wall.
- If fill material is to be used in any area, I certify that use of such fill will not adversely affect adjacent
properties. If use of fill is found to adversely affect adjacent properties, the owner may be cited for violating
the conditions of the building permit issued under the attached permit application,for lots less than one (1)
acre which are elevated by fill,an engineered drainage plan is required.
If I am the AGENT FOR THE OWNER,I promise in good faith to inform the owner of the permitting conditions set forth in this affidavit prior to
commencing construction.I understand that a separate permit may be required for electrical work,plumbing,signs,wells,pools,air conditioning,gas,or
other installations not specifically included in the application.A permit issued shall be construed to be a license to proceed with the work and not as
authority to violate,cancel,alter,or set aside any provisions of the technical codes,nor shall issuance of a permit prevent the Building Official from
thereafter requiring a correction of errors in plans,construction or violations of any codes.Every permit issued shall become invalid unless the work
authorized by such permit is commenced within six months of permit issuance,or if work authorized by the permit is suspended or abandoned for a
period of six(6)months after the time the work is commenced.An extension may be requested,in writing,from the Building Official for a period not to
exceed ninety(90)days and will demonstrate justifiable cause for the extension.If work ceases for ninety(90)consecutive days,the job is considered
abandoned.
WARNING TO OWNER: YOUR FAILURE TO RECORD A NOTICE OF COMMENCEMENT MAY RESULT IN YOUR
PAYING TWICE FOR IMPROVEMENTS TO YOUR PROPERTY.IF YOU INTEND TO OBTAIN FINANCING,CONSULT
WITH YQl'R AN ATTORNEY BEFORE RECORDING YOUR NOTICE OF COMMENCEMENT,
FLORIDA JURAT(F.S. 7.03)
OWNER OR AGE CONTRACTOR
� cri ed and swo o(or a rmed)before m this S bsc ibed and sworn to1p ff�e�i fo h1
—a --etc �� � �by Il✓1 L ac
Who is/are personar Ily known to me or has/have produced o is re personally known to me or has/have produced
as identification. as identification.
Notary Public Notary Public
Commission No. Commission No.
Name of Notary typed,printed or stamped Name of Notary typed,printed or stamped
"`;`•' PATSUSI
�P1'a.ny PAT SUSI ; MY COMMISSION#GG 216246
4, Or EXPIRES:-Aqust 26,2022
MY COMMISSION#GG 216245 '•4 E.iso'
a7?1N P4bllt UnderWll(grs
' 'r:XPIRES.August25,2022 ���
Bonded Thru Notary Public Underwriters
INSTR#2020131088 OR BK 10155 PG 2119 Page 1 of 1
08/12/2020 09:55 AM Rcpt:2192120 Rec:10.00 IDS:0.00 IT:0.00
Nikki Alvarez-Sowles,Esq.,Pasco County Clerk&Comptroller _
NOTICE OF COMMENCEMENT
Permit No.
Tax Folio No.
THE UNDERSIGNED hereby gives notice that improvement will be made to certain real property,and in accordance with
Chapter 713,Florida Statutes,the following information is provided in this NOTICE-OF COMMENCEMENT.
1.Description of property(legal description of property: Z S 'L/'d/Z D•o ad o o •/39e
a)Street(job)Address: 71 M e /l e O
2.General description of improvement(s): ; r a, e- a e o
3.Owner or Lessee information(Lessee as owner only if contracted for improvements)
a.Name and address: Jaones crr. Mn
b.Interest in property: oWAt r
c.Name and address of fee simple titleholder(if other than owner):
4.Contractor Information ,
a.Name and address: kle l 1-y P- mill-5 I4ta�� �C a e/�n�a 's'n C
b.Phone number: 7a 7) -SYO Fax No.(Opt.
5.Surety Information
a.Name and address:
b.Amount of bond$
c.Phone number: Fax No.(Opt)
6.Lender
a.Name and address:
b.Phone number:
7.Persons within the State of Florida designated by Owner upon who notices or other documents may be served as provided by
Section 713.13(1)(a)7.,Florida Statutes:
a.Name and address:
b.Phone number:
8.In addition to himself,Owner designates the following person(s)to receive a copy of the Lieno's Notice as provided in
Section 713.130)(b),Florida Statutes:
a.Name and address:
b.Phone number:
Expiration date of notice of commencement(the expiration date is 1 year from the date of recording unless a different
date is specified)
WARNING TO OWNER: ANY PAYMENTS MADE BY THE OWNER AFTER THE
EXPIRATION OF THE NOTICE OF COMMENCEMENT ARE CONSIDERED IMPROPER
PAYMENTS UNDER CHAPTER 713,PART 1,SECTION 713.13,FLORIDA STATUES,AND
CAN RESULT IN YOUR PAYING TWICE FOR IMPROVEMENTS TO YOUR PROPERTY,A
NOTICE OF COMMENCEMENT MUST BE RECORDED AND POSTED ON THE JOB SITE
BEFORE THE FIRST INSPECTION.IF:YOU INTEND TO OBTAIN FINANCING,CONSULT
WITH YOUR LENDER OR AN ATTORNEY BEFORE COMMENCING WORK OR
RECORDING YOUR NOTICE OF COMMENCEMENT.
Verification pursuant to Section 92.525,Florida Statutes.Under penalties of perjury,I declare that I have-
read the foregoing and that the facts in it are true to the best of my knowledge and beliet
I
I
i
i of or Owner's or Lessee's Authorized O�ceTMirector/Partner/Manager I
Signatory's Title/Off!
State of Florida
County of Manatee
The foregoing instrument was acknowledged before me this l) day of O�-J j5-� ,20�by
who is personally known to me or has pLWuced
and who dididid not take an oath.
(Driver's License#)
Signature o
Public-State of Florida ,; - PAT SUS!
ISSION M fiG 2181A9
Print,Type,or Stamp EXPIRES:August 25,2022
Commissioned Name of Notary Public Baww Vw No"Pyb o UmWat n
^
STATE OF FLORIDA,COUNTY¢F PASCO
THIS |STO CERTIFY THAT THE FOREGOING K5A
TRUE AND CORRECT COPY OF THE DOCUMENT
ON FILE 0ROF PUBLIC RECORD |N THIS OFFICE
WITNESS MY HAND AND C THIS
DAY OF
Lowe's Home Centers, LLC INSTALLATION CONTRACT Work Order# 31155918
Lowe's Store 1864
7921 GALL BOULEVARD Total Contract Amount $ 8,893.00
ZEPHYRHILLS, FL 33541 PLEASE READ THIS Deposit $ 0.00
877-477-1116 Due Upon Completion ,$ 8,893.00
hvacservice@rjkielty.com
Visit https://www.lowes.com/licensenumbers for license information
Customer Name&Project Address Customer Address(if different) Primary Phone (276) 728-8243
James Griffin James Griffin Alternate Phone (276)728-8243
7918 MERCHANTVILLE CIR 7918 Merchantville Cir. Email james.griffin@tesinclic.com
ZEPHYRHILLS, FL 33540 zephyrhills, FL 33540
This installation contract (the "Contract') between the customer identified above ("You") and Lowe's provides for the Goods and
Installation Services specified in Estimate # 31155918-1 to be performed at the Project Address above and includes (a) any
applicable State Addendum, (b) the Notices, (c) the Terms and Conditions, and (d) Change Orders, if applicable.. If there is any
inconsistency between the State Addendum and the Notices or Terms and Conditions, the State Addendum shall take
precedence.
This Contract defines what You can expect in Your installation experience with Lowe's, what Lowe's expects in return, and how
You and Lowe's will resolve any differences. It is a legal agreement. By signing this Contract, clicking "I agree," or by accepting
Goods or Installation Services You are agreeing to be bound by this Contract. IF YOU DO NOT AGREE TO ALL OF THE
TERMS OF THIS CONTRACT,YOU MUST NOT SIGN THIS CONTRACT, CLICK 1-1 AGREE", OR ACCEPT THE GOODS OR
INSTALLATION SERVICES.
PAYMENT OPTIONS (Subject to fund verification and/or credit approval).You may pay the Total Contract Amount by
authorizing an electronic checking account withdrawal or utilizing an accepted credit card or financing. Upon electronic execution
of the Contract, You authorize the processing of the Deposit payment, if applicable, from the designated checking, credit card or
finance account. Upon completion of the Installation Services, You agree to pay the Due Upon Completion payment.You are
subject to the terms and conditions of the cardholder or financing agreement, as applicable, to which Lowe's is not a parry. Any
interest payments or other finance charges will be determined by such cardholder or financing agreement and will be in addition to
Your payments under this Contract.
FLORIDA'S LIEN LAW NOTICE. ACCORDING TO FLORIDA'S CONSTRUCTION LIEN LAW
(SECTIONS 713.001-713.37, FLORIDA STATUTES), THOSE WHO WORK ON YOUR PROPERTY OR
PROVIDE MATERIALS AND SERVICES AND ARE NOT PAID IN FULL HAVE A RIGHT TO ENFORCE
THEIR CLAIM FOR PAYMENT AGAINST YOUR PROPERTY. THIS CLAIM IS KNOWN AS A
CONSTRUCTION LIEN. IF YOUR CONTRACTOR OR A SUBCONTRACTOR FAILS TO PAY
SUBCONTRACTORS, SUB-SUBCONTRACTORS, OR MATERIAL SUPPLIERS, THOSE PEOPLE WHO
ARE OWED MONEY MAY LOOK TO YOUR PROPERTY FOR PAYMENT, EVEN IF YOU HAVE
ALREADY PAID YOUR CONTRACTOR IN FULL. IF YOU FAIL TO PAY YOUR CONTRACTOR, YOUR
CONTRACTOR MAY ALSO HAVE A LIEN ON YOUR PROPERTY. THIS MEANS IF A LIEN IS FILED
YOUR PROPERTY COULD BE SOLD AGAINST YOUR WILL TO PAY FOR LABOR, MATERIALS, OR
OTHER SERVICES THAT YOUR CONTRACTOR OR A SUBCONTRACTOR MAY HAVE FAILED TO
PAY. TO PROTECT YOURSELF, YOU SHOULD STIPULATE IN THIS CONTRACT THAT BEFORE ANY
PAYMENT IS MADE, YOUR CONTRACTOR IS REQUIRED TO PROVIDE YOU WITH A WRITTEN
RELEASE OF LIEN FROM ANY PERSON OR COMPANY THAT HAS PROVIDED TO YOU A "NOTICE
TO OWNER." FLORIDA'S CONSTRUCTION LIEN LAW IS COMPLEX, AND IT IS RECOMMENDED
THAT YOU CONSULT AN ATTORNEY.
LIEN WAIVER: if You make all payments as required under this Contract, Lowe's hereby waives its right to file a mechanics
and/or materialmen's lien and will protect Customer's property from any such lien filed by any person, including Installer, in
connection with the Installation Services.
NOTICES
TIME OF SERVICE.The Installation Services are estimated to start thirty days from the transaction date, based on the reasonable
availability of the Installer and any special order or custom materials, if applicable. The Installation Services are estimated to be
completed sixty days from the transaction date.
Doc ID: le3b2dl413ede5a3b385514021715c4a46b02783
PRICE CALCULATIONS. If this Contract includes Goods and related Installation Services sold by unit of measurement, such as
per square foot, the Price may include more Goods than the actual measurements of Your project area. The Price includes the
total amount of Goods required by Lowe's to fulfill the Contract(including surplus materials and overages) (together the
"Estimated Product")and the Installation Services required based upon this total amount of Goods. For instance, a 120 square
foot room may require 140 square feet of carpet, and the Price would include Installation Services based upon the 140 square
feet of carpet. The total amount of Estimated Product is based upon the total Goods recommended by the Installer, based on the
Installer's assessment of unique characteristics of Your project. If any usable Goods are left over, Lowe's may, at its discretion,
initiate a Price adjustment. Lowe's will not adjust the Total Contract Amount for the related Installation Services. By signing this
Contract You acknowledge You are aware of Your project area measurements and the amount of Estimated Product, and that the
Estimated Product may exceed Your actual project area.
LEAD SAFE INFORMATION. Federal and applicable state laws require that You be provided with a lead hazard information
pamphlet such as the Renovate Right: Important Lead Hazard Information for Families, Child Care Providers and Schools. By
signing this Contract, You acknowledge having received a copy of this information pamphlet before work began informing You of
the potential risk of the lead hazard exposure from renovation activity performed in Your dwelling unit or facility. A copy of the
pamphlet is available at the following website: https://www.epa. ov/sites/production/files/documents/renovaterightbrochure.pdf.
ARBITRATION AGREEMENT. This Contract provides that You and Lowe's will resolve all claims by BINDING ARBITRATION.
You and Lowe's GIVE UP THE RIGHT TO GO TO COURT to enforce this Contract(EXCEPT for matters that may be taken to
SMALL CLAIMS COURT). A NEUTRAL ARBITRATOR will determine Lowe's and Your rights and NOT a judge or jury. You and
Lowe's are entitled to a FAIR HEARING. BUT the arbitration procedures are SIMPLER AND MORE LIMITED THAN RULES
APPLICABLE IN COURT. Arbitrator decisions are as enforceable as any court order and are subject to VERY LIMITED REVIEW
BY A COURT. FOR MORE DETAILS: Review the sections titled ARBITRATION AGREEMENT, WAIVER OF JURY TRIAL AND
WAIVER OF CLASS ACTION ADJUDICATION found in the Terms and Conditions of this Contract.
PHOTO RELEASE. By signing this Contract, You grant to Lowe's, its representatives, and Installer the right to take and use
photographs, videos, or other representations of the Project Address before and after the Installation Services and all work
performed at the Project Address related to this Contract(the"Content"). Lowe's irrevocably keeps all rights (including the
copyright), title, and interest in the Content for use in all markets and media, worldwide, in perpetuity. Lowe's can use the Content,
in any form or medium, internally for any purpose (e.g., customer service, planning, and claims).
TERMS AND CONDITIONS
1. COMMON DEFINITIONS. Capitalized terms used in this Contract will either have the following stated meanings or will be
defined throughout the Contract.
a) "You", "Your(s)", and "Customer" all mean the person executing this Contract to purchase Installation Services.
b) "Goods" means the physical items You are purchasing in connection with the Installation Services. A list of the Goods
appears on the Estimate.
c) "Installation Services" means the work, labor, and other services necessary to install the Goods. Some examples of
Installation Services include delivery, handling, return, and selection and placement of Goods.
d) "Installer" means the independent contractor Lowe's arranges to perform the Installation Services. Installer will be
licensed when legally required, and will direct, control, and perform the Installation Services directly or through its employees,
agents, and subcontractors using tools and equipment Installer provides. Lowe's does not employ Installer, its employees, or its
agents or subcontractors.
e) "Lowe's" means Lowe's Home Centers, LLC, a North Carolina Limited Liability Company located at 1605 Curtis Bridge
Road, Wilkesboro, NC 28697. Lowe's Employer Identification Number is 56-0748358.
2. SCOPE.This Contract is between You and Lowe's for the purchase of Goods and Installation Services. Lowe's does not
perform Installation Services, but arranges for Installer to do so directly or through Installer's employees, agents, or
subcontractors. Installer is an independent contractor and is not under the supervision or control of Lowe's. Installation Services
do not include architectural or engineering services. Installer will complete Installation Services, subject to any changes, in
substantial conformance with the Merchandise and Installation Summary. Lowe's reserves the right to terminate or rescind this
Contract if Lowe's decides that any portion of the job is beyond the scope of the Installation Services that Lowe's originally
contemplated.
3. CHANGE ORDERS. Any changes to the Goods and/or Installation Services, including but not limited to changes necessitated
by undisclosed, unidentified or unforeseen conditions on the site ("Undisclosed Conditions"), are subject to a written Change
Order,which shall specify the change in scope and any adjustment to the Total Contract Amount, which will be reflected in the
Due Upon Completion payment. Neither Lowe's nor Installer shall have any obligation to remediate any such conditions and, at
its discretion, Lowe's may immediately discontinue the installation or ask for a Change Order. Neither Lowe's nor Installer will
remediate any mold, asbestos or lead-based paint and are not responsible for any delays caused by events beyond either party's
control, including but not limited to acts of nature, governmental actions, delivery delays, or delays caused by third parties, labor
strikes, project financing, incorrect information provided by You or Your non-compliance with this Contract.
4. GOODS. Title to Goods does not pass to You and remains the property of Lowe's until Goods are installed in Your home,
Doc ID: 1e3b2d1413ede5a3b385514021715c4a46b02783
building, or on Your property. You agree that the Contract is being offered for the Total Contract Amount and that any surplus
materials upon completion of the Installation Services are not Your property and, if instructed by Lowe's, such surplus materials
shall be returned to Lowe's by the Installer. Upon request from You at the time of job completion, Lowe's, in its discretion, may
allow all or part of the unused, receipted surplus materials to be retained by You.
6. LICENSES, PERMITS,AND OTHER REGULATORY REQUIREMENTS. Installer will obtain any and all licenses,
registrations, certifications, and permits ("Local Requirements") necessary to perform the Installation Services at the Project
Address, unless otherwise required by law or where Lowe's elects to use a third-party service. You agree to pay any fees
associated with the Local Requirements and to cooperate in any required inspection or permitting process. The Installer, and not
Lowe's, is responsible for performing the Installation Services in compliance with applicable safety rules, building codes, zoning
ordinances, and other regulations ("Local Regulations"). You are responsible for any violations of the Local Regulations that
exist at the time You sign this Contract. This Contract creates no obligation to correct these pre-existing violations. Any change
in the Local Regulations may require a Change Order and may result in an increase in the Total Contract Amount. Neither
Lowe's nor Installer will perform any additional work after completion of the Installation Services due to changes in the Local
Regulations.
6. TERMINATION. If You breach this Contract or decline a reasonable Change Order request, Lowe's may immediately terminate
this Contract without further obligation. In the event of such termination, You agree to pay Lowe's the costs of materials, labor,
expenses, and services provided by Lowe's in connection with the Installation Services through the date of termination, plus any
other amounts set forth in this Contract or allowed under applicable law. If terminated or rescinded, Lowe's has no obligation to
return the Project Address to the original condition. If Lowe's terminates or rescinds the contract before delivering Goods or
beginning the Installation Services, then Lowe's will return the portion of the Total Contract Amount paid by You without further
costs or obligation to You or Lowe's. If Lowe's terminates or rescinds the contract after delivering Goods or beginning the
Installation Services, title of the Goods passes to You upon termination and Lowe's has no obligation to return any portion of the
Total Contract Amount to You except in exchange for Goods You validly return. You will have thirty (30) days from any termination
or rescission to return any standard Goods in the original, unopened condition for refund or credit. Returns may be subject to a
fifteen percent(15%) restocking fee. Custom and special-order Goods are not returnable. Custom Goods include Goods altered,
color-matched, shaped, sized, cut, or otherwise designed or fitted to accommodate the requirements of a particular space or
environment. Some examples of custom Goods are cabinets, countertops, floor and wall coverings, and window treatments.
7. YOUR WARRANTY TO LOWE'S AGAINST VIOLATIONS OF EASEMENTS, COVENANTS,AND THIRD PARTY RIGHTS.
You warrant that performance of the Installation Services will not violate any existing real property easement, covenant, historic
district regulations, homeowner's association rule or rights of third parties holding an interest in the Project Address or otherwise,
and that You have the rights and authority to enter into this Contract.
8. CUSTOMER RESPONSIBILITIES. You agree:
a) To Pay only Lowe's.You agree to pay Lowe's and only Lowe's for any Goods and Installation Services, even if Installer
provides a new Contract or Change Order for your review and signature. Installation Made Easy, Inc. is the only party authorized
to collect payment on behalf of Lowe's. You agree not to pay the Installer separately or directly. This Contract is solely between
You and Lowe's.
b) To Locate Lines and Hazards. Before Installer begins Installation Services, You will identify and mark the location of
utility lines, for example electrical, plumbing, and gas lines, and property lines that could impact the Installation Services. Prior to
the,installation, You will identify any pre-existing physical or environmental hazards, building code violations or other legal
encumbrances that could affect the Installation Services. You are responsible for any delays or interference to the installation
caused by You or any third party under Your direction or control.
c) To Ensure Compliance with Smoke Alarm and Carbon Monoxide Detector Requirements. Prior to the start of the
Installation Services, You will ensure the Project Address has all necessary carbon monoxide detectors and smoke alarms
("Detectors") needed for the Installer to obtain the necessary permits and complete the Installation Services. You are solely
responsible for the proper number, placement, type, functioning, operation, installation, testing, as per the manufacturers'
specifications, and maintenance of any Detectors required by Local Regulations. Failure to meet Federal, state or local Detector
requirements, if any, will be considered an Undisclosed Condition.
d) To Provide a Safe and Proper Working Environment. Before and during the Installation Services, You will'ensure that
work areas are free of vermin, pre-existing physical or environmental hazards, and violations of Local Regulations. You will allow
the Installer to have access to work areas and restrooms. You will provide climate control, where applicable, and electricity to the
work areas. You agree not to allow unattended minors at the Project Address during the Installation Services. You agree to
control and keep pets away from work areas. You agree to keep posted permits on display at all times. If You or someone You
control interferes with the In Services, Lowe's may charge You for storage, transportation, or other resulting charges.
e) To Sign the Certificate of Completion. You will sign a Completion Certificate upon satisfactory completion of the
Installation Services.
f) Not to Assign or Transfer this Contract. You cannot give Your rights under this Contract to anyone else,
g) To Promptly Notify Lowe's of a Claim. If you have a claim that is in any way related to this Contract, You must make
that claim to Lowe's within thirty (30) calendar days of when you knew or should have known of a problem. Lowe's will attempt
resolution of any claim(s)within sixty(60)calendar days of receiving Your notice.
h) That You Are Responsible If You Choose to Help. IF YOU CHOOSE TO HELP, YOU ASSUME THE RISK AND THE
Doc ID: 1e3b2d1413ede5a3b385514021715c4a46b02783
FULL LIABILITY OF PHYSICALLY ASSISTING WITH DELIVERY OF THE GOODS OR WITH PERFORMANCE OF THE
INSTALLATION SERVICES.
9. LIMITED WARRANTY.TO THE EXTENT PERMISSIBLE UNDER APPLICABLE LAW, LOWE'S WARRANTS THE
WORKMANSHIP OF THE INSTALLATION SERVICES FOR ONE (1) YEAR FROM THE COMPLETION DATE (THE
"WARRANTY PERIOD"). THIS WARRANTY DOES NOT COVER DAMAGE CAUSED BY ACTS OF GOD, INSTALLATION OR
REPAIRS MADE BY PERSONS OTHER THAN INSTALLER, OR ABUSE, MISUSE, NEGLECT OR NORMAL WEAR AND TEAR.
GOODS ARE COVERED EXCLUSIVELY BY THE MANUFACTURER'S WARRANTY, IF ANY. THIS LIMITED WARRANTY
GIVES YOU SPECIFIC LEGAL RIGHTS. YOU MAY HAVE OTHER RIGHTS THAT VARY FROM STATE TO STATE. LOWE'S
WARRANTY FOR INSTALLATION SERVICES IS IN LIEU OF ANY OTHER WARRANTY, EXPRESS OR IMPLIED, INCLUDING
WITHOUT LIMITATION ANY IMPLIED WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE.
10. LIMITATION OF LIABILITY. For any claim related to this Contract, You can only seek recourse from Lowe's or the Installer,
no parent or affiliate of Lowe's shall have any liability under this Contract. You must give Lowe's written notice within the Warranty
Period of any warranty claim. Your only remedy for a warranty claim is either(1)for Lowe's to have the Installation Services
performed again, including any necessary repair and replacement of Goods, to correct the defective Installation Services, or(ii) a
refund of all or part of the Total Contract Amount. Lowe's has absolute discretion to choose between these two options.
YOU SHALL HAVE NO OTHER REMEDY FOR A WARRANTY CLAIM, INCLUDING WITHOUT LIMITATION REMEDY FOR
LOSS OR DAMAGE CAUSED BY NORMAL WEAR AND TEAR, LOSS OR DAMAGE WHICH HAS NOT BEEN REASONABLY
MITIGATED, OR LOSS OR DAMAGE CAUSED BY ACTS OF GOD. IN NO EVENT SHALL LOWE'S BE LIABLE FOR
INDIRECT, PUNITIVE, CONSEQUENTIAL OR INCIDENTAL DAMAGES (SUCH AS,WITHOUT LIMITATION, LOST PROFITS,
LOST SALES, COSTS ASSOCIATED WITH PROJECT DELAYS,AND INJURIES TO PERSONS OR PROPERTY), EVEN
WHERE LOWE'S HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.WHERE, DUE TO OPERATION OF
LAW, SUCH DAMAGES CANNOT BE EXCLUDED,THEY ARE EXPRESSLY LIMITED IN AMOUNT TO THE TOTAL
CONTRACT AMOUNT. For warranty claims, You agree to prepare the work area at the Project Address in the manner described
in the section titled "Customer Responsibilities."
11. ARBITRATION AGREEMENT,WAIVER OF JURY TRIAL,AND WAIVER OF CLASS ACTION RIGHTS. Lowe's wants to
keep You as a customer, and Lowe's resolves most questions and complaints informally. All claims related to this Contract by
Lowe's or by You, Your agents, insureds or assigns, which You and Lowe's cannot resolve informally shall proceed to binding
arbitration conducted by a single arbitrator under the current applicable rules, procedures, and protocols of JAMS, Inc. ("JAMS")
(www.iamsadr.com)or the American Arbitration Association ("AAA") (www.adr.or4). You agree that if either JAMS or AAA is
unable or unwilling to arbitrate the matter, You and Lowe's will agree upon a single arbitrator with a nationally recognized
arbitration.firm to arbitrate the matter. Claims subject to binding arbitration include:
a) all claims in any way related to the signing of this arbitration agreement, the validity or scope of this arbitration agreement,
or any attempt to set aside this arbitration agreement;
b) all federal or state law claims relating in any way to this Contract(including this arbitration agreement), the information
You gave Lowe's before entering into this Contract, and any past agreement or agreements between You and Lowe's;
c) all counterclaims, cross-claims, and third-party claims;
d) all common law claims of any kind including claims based upon alleged product defect, contract, tort, fraud, or other
intentional torts;
e) all claims based upon a violation of any state or federal constitution, statute, or regulation;
f) all claims asserted by Lowe's against You, including claims for money damages to collect any sum Lowe's claims You
owe;
g) all claims asserted by You individually against Lowe's or any of Lowe's employees, agents, directors, officers,
shareholders, managers, members, parent company, or affiliated entities (collectively the"related third parties") or the Installer,
including claims for money damages and/or equitable or injunctive relief,
h) all claims asserted on Your behalf by another person;
i) all claims asserted by or on behalf of You as a private attorney general against Lowe's, related third parties or the
Installer;
j) all claims arising from or relating directly or indirectly to the disclosure by Lowe's, related third parties or the Installer of
any non-public personal information about You; and
k) all other claims related to this Contract whether or not set forth above. If the dispute falls within the jurisdiction of a small
claims court the claimant may, at its option, choose to arbitrate or file a small claims action. Any appeal of a judgment from a
small claims court shall be resolved by arbitration as provided by this Contract.
Binding arbitration means that You waive: (1) any right to a jury trial; (2)any right to bring a lawsuit in a court(other
than a small claims court as described above); and (3) any right to seek relief in any other way.An arbitrator will decide
any claim not decided by a small claims court.You agree that binding arbitration provides a simple, cost effective
method to resolve disputes quickly.
You agree that(1)You cannot pursue a class action lawsuit or class action arbitration of any type,(2) no one can pursue
a class action lawsuit or class action arbitration of any type on Your behalf, and (3)a Court or arbitrator(s)cannot order
class action proceedings under this Contract. You further agree that there shall be no joinder of parties, except for
Doc ID:1e3b2d1413ede5a3b385514021715c4a46b02783
joinder of parties to the transaction covered by this Contract. By agreeing to binding arbitration You and Lowe's waive
any right to bring or participate in a class action lawsuit or class action arbitration regarding any claim.
How Arbitration Works:
Lowe's may demand arbitration by sending written notice to You at the address listed in this Contract. You may demand
arbitration by sending written notice to Lowe's at the following address: Mail code NB6LG, P.O. Box 1000, Mooresville, NC 28115.
The arbitration shall occur in the city or county of the Project Address. Lowe's shall pay the filing, administrative, hearing, and
arbitrator's fees associated with the arbitration. You are not required to reimburse Lowe's for these expenses even if Lowe's wins
the arbitration. Unless the arbitrator's award or controlling law specifically provides otherwise, You and Lowe's are each
responsible for their own attorneys'fees and other expenses, such as witness and expert witness fees. Either party may request
that the arbitrator provide a written explanation of the award, consistent with the then current rules, procedures, and protocols of
the arbitration entity selected by the parties. Any court having jurisdiction may receive and enforce the arbitrator's award. If You
fail to pay Lowe's in accordance with this Contract, You agree that Lowe's can recover its reasonable attorneys'fees as provided
by N.C. Gen. Stat. Section 6-21.2 or other controlling law. The parties agree that this arbitration agreement is made in connection
with a transaction involving interstate commerce and that the Federal Arbitration Act, 9 U.S.C. Sections 1-16 (as amended)
("FAA"), governs. If for any reason the Federal Arbitration Act does not apply, then the laws of the State of North Carolina shall
govern this arbitration agreement.
12. GOVERNING LAW AND SEVERABILITY. North Carolina law shall govern and guide the interpretation of this Contract,
without regard to the choice of law rules of any state, except that the FAA governs the ARBITRATION AGREEMENT, WAIVER
OF JURY TRIAL AND WAIVER OF CLASS ACTION RIGHTS. Should an arbitrator, court, or other interpreting entity determine
that a provision of this Contract is contrary to an applicable law, such unlawful provision shall be ineffective without invalidating
the other provisions, which shall remain in full force and effect.
FLORIDA ADDENDUM
1. FLORIDA CONTRACTOR LICENSES AND CERTIFICATIONS. Contractor license number(s) and certifications held by or on
behalf of Lowe's Home Centers, LLC: #CCC1326824 (Certified Roofing Contractor), #CGC1508417 (Certified General
'Contractor), #CRC1327732 (Certified Residential Contractor), #FR04517 and#FRO1584 (Construction Financial Officer).
License number(s) and certifications may be subject to change in accordance with local or state government processes. For the
most current listing of license numbers and certifications held by or on behalf of Lowe's Home Centers, LLC please visit
http://www.lowes.com/licensenumbers.
2. FLORIDA HOME OWNERS' CONSTRUCTION RECOVERY FUND. PAYMENT UP TO A LIMITED AMOUNT, MAY BE
AVAILABLE FROM THE FLORIDA HOMEOWNERS' CONSTRUCTION RECOVERY FUND IF YOU LOSE MONEY ON A
PROJECT PERFORMED UNDER CONTRACT, WHERE THE LOSS RESULTS FROM SPECIFIED VIOLATIONS OF FLORIDA
LAW BY A LICENSED CONTRACTOR. FOR INFORMATION ABOUT THE RECOVERY FUND AND FILING A CLAIM,
CONTACT THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD AT THE FOLLOWING TELEPHONE NUMBER
AND ADDRESS: 1940 NORTH MONROE STREET, TALLAHASSEE, FL 32399-0783; PHONE: (850)487-1395.
3. CHAPTER 668 NOTICE OF CLAIM. ANY CLAIMS FOR CONSTRUCTION DEFECTS ARE SUBJECT TO THE NOTICE AND
CURE PROVISIONS OF CHAPTER 558, FLORIDA STATUTES.
4. MIAMI-DADE COUNTY RESIDENTS ONLY. WARNING TO OWNER IF INSTALLATION SERVICES ARE PERFORMED
WITHIN MIAMI-DADE COUNTY: UNDER FLORIDA LAW, YOUR FAILURE TO MAKE SURE THAT LOWE'S AND INSTALLER
(INCLUDING ALL SUBCONTRACTORS RETAINED BY INSTALLER)ARE PAID MAY RESULT IN A LIEN AGAINST YOUR
PROPERTY AND YOUR PAYING TWICE. TO AVOID A LIEN AND PAYING TWICE, EVERY TIME YOU PAY LOWE'S, YOU
MUST OBTAIN A WRITTEN RELEASE FROM (1) LOWE'S, INSTALLER AND (111)ALL SUBCONTRACTORS RETAINED BY
INSTALLER.
6. NOTICE TO MIAMI-DADE RESIDENTS ONLY. If Installation Services are performed within Miami-Dade
County, YOU ARE ADVISED THAT THE COUNTY CONSTRUCTION TRADES QUALIFYING BOARD
AND THE BUILDING AND ZONING DEPARTMENT OF MIAMI-DADE COUNTY, AND THE STATE OF
FLORIDA DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION MAY HAVE
INFORMATION ON FILE CONCERNING THE FINANCIAL RESPONSIBILITY AND ANY COMPLAINTS
AND INVESTIGATIONS PERTAINING TO LOWE'S AND/OR INSTALLER. THE PUBLIC RECORDS OF
THE COUNTY ARE AVAILABLE FOR INSPECTION AND COPYING. IN ORDER TO PROTECT
YOURSELF, YOU ARE ALSO ADVISED AS FOLLOWS: (1) YOU MAY REQUEST THAT THIS
CONTRACT ALLOW FOR PAYMENTS TO LOWE'S TO BE CONDITIONED UPON LOWE'S OBTAINING
AND PASSING MANDATORY INSPECTIONS; (II) YOU MAY PAY THE COST OF PURCHASING AN
INSTALLER'S PAYMENT BOND OR OTHER SECURITY (AND MAY OBTAIN COPIES OF THE SAME
UPON REQUEST), TO COVER PAYMENTS TO SUBCONTRACTORS AND MATERIAL SUPPLIERS, IN
THE EVENT LOWE'S OR INSTALLER FAILS TO DO SO; (III) YOU MAY REQUEST THAT THIS
Doc ID: 1e3b2d1413ede5a3b385514021715c4a46b02783
CONTRACT CONTAIN A WORK OF COMPLETION DATE, IN THE ABSENCE OF A COMPLETION
DATE, YOU MAY REQUEST THAT INTERIM MILESTONES OR.TIME PERIODS BE ESTABLISHED FOR
COMPLETION OF PORTIONS OF THE INSTALLATION SERVICES; (IV) IF, AFTER OBTAINING A
PERMIT FOUR TH9 WORK, LOWE'S TERMINATES THIS CONTRACT WITHOUT JUST CAUSE OF
FAILS TO PERFORM THE INSTALLATION SERVICES WITHOUT JUST CAUSE FOR THIRTY (30)
CONSECUTIVE DAYS, THE PROJECT MAY BE CONSIDERED ABANDONED, WHICH CONSTITUTES
A PENALTY FOR WHICH A CONTRACTOR MAY BE DISCIPLINED BY THE STATE OF BY THE
COUNTY; AND (V) LOWE'S HAS COMMERCIAL GENERAL LIABILITY INSURANCE, COMMERCIAL
AUTOMOBILE LIABILITY INSURANCE AND WORKERS' COMPENSATION INSURANCE AS
REQUIRED BY APPLICABLE STATUTE, THROUGH INSURERS RATED A/X OR HIGHER BY A.M.
BEST AND AUTHORIZED TO DO BUSINESS IN THE STATE OF FLORIDA. WITH LIMITED
EXPIATIONS PROVIDED BY LAW, THE WORK YOU ARE CONTRACTING FOR MUST BE
PERFORMED BY A STATE OF FLORIDA CERTIFIED CONTRACTOR OR A MIAMI COUNTY
CERTIFIED CONTRACTOR WHO IS ALSO REGISTERED WITH THE STATE.
NOTICE OF RIGHT TO CANCEL. If this is a"home solicitation sale,"and if Customer does not want the Goods or
Installation Services, Customer may cancel this Contract by providing written notice to Lowe's in person or by mail.
This notice must indicate that Customer does not want the Goods or Installation Services and must be delivered or
postmarked before midnight of the third business day after Customer signs this Contract. If Customer cancels this
Contract, Lowe's may not keep all or part of any cash down payment. See the notice of cancellation form sent as an
attachment to this Contract for an explanation of this right. By executing this Contract, Customer acknowledges receipt
of two (2)completed copies of the Notice of Right to Cancel form and certifies Lowe's has informed Customer orally of
his or her right to cancel.
ELECTRONIC SIGNATURE AND ACCEPTANCE: By electronically signing below, Customer acknowledges and agrees that(1)
Customer has read, understands and voluntarily accepts the terms of this Contract; (2)this is the entire Contract between
Customer and Lowe's regarding the Installation Services; and (3)this Contract supersedes all prior discussions and agreements,
either oral or written, relating to the Installation Services. This Contract cannot be assigned except by writing signed by Customer
and Lowe's. Customer will receive an electronic copy of this Contract upon acceptance.
IlWe electronically consent to the terms and conditions of this Contract.
Lowe's Authorized Representative
08/05/2020
Signature Date
Customer
08/05/2020
Signature Date
After signing the agreement, scroll to the top and click CONTINUE.
Doc ID: 1e3b2d1413ede5a3b385514021715c4a46b0278�I