Loading...
HomeMy WebLinkAbout22-4781City of Zephyrhills 5335 Eighth Street Zephyrhills, FL 33542 ELCMISC-004781-2022 Phone: (813) 780-0020 Fax: (813) 780-0021 Issue Date: 09/09/2022 1111 11111111 11 1111!11 ZT: i i i 11 �1 �� 32 25 210050 01600 0130 35996 Morse Willow Court J 7 77 Name: ANDRES PARKA & CYNTHIA Permit Type: Electric Service Replacement/M Contractor: ADT SOLAR LLC RIVERO PARKA Class of Work: Add/Alter Residential Address: 35996 Morse Willow Ct Building Valuation: $1.00 ZEPHYRHILLS, FL 33541 Electrical Valuation: $52,280.00 1 . . ........... Phone: (813) 770-2246 Mechanical Valuation: 141111 Plumbing Valuation: Total Valuation: $52,281.00 Total Fees: $301.40 Amount Paid: $301.40 Date Paid: 9/30/2022 12:52:54PM INSTALLATION ROOF MOUNT SOLAR PV Electrical Permit Fee $301.40 REINSPECTION FEES: (c) With respect to Reinspection fees will comply with Florida Statute 553.80(2)(c) the local 1government shall impose a fee of four times the amount of the fee imposed for the initial inspection or first reinspection, whichever is greater, for each subsequent reinspection. Notice: In addition to the requirements of this permit, there may be additional restrictions applicable to this property that may be found in the public records of this county, and there may be additional permit required from other governmental entities such as water management, state agencies or federal agencies. "Warning to owner: Your failure to record a notice of commencement may result in your paying twice for improvements to your property. If you intend to obtain financing, consult with your lender or an attorney before recording your notice of commencement." Complete Plans, Specifications add fee Must Accompany Application. All work shall be performed in accordance with City Codes and Ordinances. NO OCCUPANCY BEFORE C.O. NO OCCUPANCY BEFORE C.O. rii� 90''A 1,11 Ri U X" 9 1 I I a 813-780-0020 City of Zephyrhilis Permit Application Fax-813-780-0021 Building Department Date Received Phone Contact for Permitting a * * A 4 111 1 4, i**W&W2192411 Owner's Name Andres Parra Owner Phone Number Owner's Address 35996 Morse Willow Ct, Zl_h �rhllll, FL �335 1 Owner Phone Number Fee Simple Titleholder Name Owner Phone Number Fee Simple Titleholder Address JOB ADDRESS 1 35996 Morse Willow Ct, Zephyrhills, FL 33541 LOT # SUBDIVISION ISILVERADO RANCH PARCELID# 0-01600-0130 (OBTAINED FROM PROPERTY TAX NOTICE) WORK PROPOSED R NEW CONSTRF--] ADDIALT SIGN DEMOLISH INSTALL REPAIR PROPOSED USE SFR COMM OTHER Oar TYPE OF CONSTRUCTION BLOCK FRAME STEEL DESCRIPTION OF WORK Installation of PV solar panels on existing roof, BUILDING SIZE SQ FOOTAGE= HEIGHT BUILDING N-52 280 001 VALUATION OF TOTAL CONSTRUCTION =ELECTRICAL AMP SERVICE PROGRESS ENERGY W.R,E,C. =PLUMBING =MECHANICAL 1$ VALUATION OF MECHANICAL INSTALLATION =GAS ROOFING SPECIALTY = OTHER FINISHED FLOOR ELEVATIONS E= FLOOD ZONE AREA =YES NO ADT Solar LLC BUILDER COMPANY SIGNATURE REGISTERED [XLLN J FEE CURREN Address 4492 Eagle Falls PL Tampa FL 33619 1 License # ELECTRICIAN COMPANY ADT Solar LLC SIGNATURE REGISTERED Y / N FEE CURREN L�Y / N Address 4492 Eagle Falls PL Tampa FL 33619 License# [ EC13001242 PLUMBER COMPANY SIGNATURE REGISTERED L_Z_LN J FEE CURREN Y/N Address License# MECHANICAL COMPANY SIGNATURE REGISTERED FEEL CURREN Y 1N Address License 4 OTHER COMPANY SIGNATURE REGISTERED YIN FEE CURREN Address License# RESIDENTIAL Attach (2) Plot Plans; (2) sets of Building Plans; (1) set of Energy Forms; R-O-W Permit for new construction, Minimum ten (10) working days after submittal date. Required onsite, Construction Plans, Stormwater Plans w/ Silt Fence installed, Sanitary Facilities & 1 dumpster; Site Work Permit for subdivisions/large projects COMMERCIAL Attach (2) complete sets of Building Plans plus a Life Safety Page; (1) set of Energy Forms. R-O-W Permit for new construction. Minimum ten (10) working Bays after submittal date. Required onsite, Construction Plans, Stormwater Plans wl Silt Fence installed, Sanitary Facilities & 1 dumpster. Site Work Permit for all new projects. All commercial requirements must meet compliance SIGN PERMIT Attach (2) sets of Engineered Plans. -*PROPERTY SURVEY required for all NEW construction, Directions: Fill out application completely. Owner & Contractor sign back of application, notarized If over $2500, a Notice of Commencement is required. (AIC upgrades over $7500) Agent (for the contractor) or Power of Attorney (for the owner) would be someone with notarized fetterfrom owner authorizing same OVER THE COUNTER PERMITTING (copy of contract required) Reroofs if shingles Sewers Service Upgrades A/C Fences (PI ot/S urvey/ Footage) Driveways -Not over Counter if on public roadways..needs ROW 813-780-0020 City of Zephyrhills Permit Application Fax-813-780-0021 Building Department NOTICE OF DEED RESTRICTIONS: The undersigned understands that this permit may be subject to "deed" restrictions" which may be more restrictive than County regulations. The undersigned assumes responsibility for compliance with any applicable deed restrictions. UNLICENSED CONTRACTORS AND CONTRACTOR RESPONSIBILITIES: If the owner has hired a contractor or contractors to undertake work, they may be required to be licensed in accordance with state and local regulations. If the contractor is not licensed as required by law, both the owner and contractor may be cited for a misdemeanor violation under state law. If the owner or intended contractor are uncertain as to what licensing requirements may apply for the intended work, they are advised to contact the Pasco County Building Inspection Division ---Licensing Section at 727-847- 8009, Furthermore, if the owner has hired a contractor or contractors, he is advised to have the contractor(s) sign portions of the "contractor Block" of this application for which they will be responsible. If you, as the owner sign as the contractor, that may be an indication that he is not properly licensed and is not entitled to permitting privileges in Pasco County. TRANSPORTATION IMPACT/UTILITIES IMPACT AND RESOURCE RECOVERY FEES: The undersigned understands that Transportation Impact Fees and Recourse RecoveryFees may apply to the construction of new buildings. change of use in existing buildings, or expansion of existing buildings, as specified in Pasco County Ordinance number 89-07 and 90-07, as amended. The undersigned also understands, that such fees, as may be due, will be identified at the time of permitting. It is further understood that Transportation Impact Fees and Resource Recovery Fees must be paid prior to receiving a "certificate of occupancy" or final power release. If the project does not involve a certificate of occupancy or final power release, the fees must be paid prior to permit issuance. Furthermore, if Pasco County Water"Sewer Impact fees are due, they must be paid prior to permit issuance in accordance with applicable Pasco County ordinances. CONSTRUCTION LIEN LAW (Chapter 713, Florida Statutes, as amended): If valuation of work is $$2,500.00 or more, I certify that I, the applicant, have been provided with a copy of the "Florida Construction Lien Law —Homeowners Protection Guide" prepared by the Florida Department of Agriculture and Consumer Affairs. If the applicant is someone other than the "owner I certify that I have obtained a copy of the above described document and promise in good faith to deliver it to the "owner' prior to commencement. CONTRACTOR'S/OWNER'S AFFIDAVIT: I certify that all the information in this application is accurate and that all work will be done in compliance with all applicable laws regulating construction, zoning and land development. Application is hereby made to obtain a permit to do work and installation as indicated. I certify, that no work or installation has commenced prior to issuance of a permit and that all work will be performed to meet standards of all laws regulating construction, County and City codes, zoning regulations, and land development regulations in the jurisdiction. I also certify that I understand that the regulations of other government agencies may apply to the intended work, and that it is my responsibility to identify what actions I must take to be in compliance. Such agencies include but are not limited to: Department of Environmental Protection -Cypress Bayheads, Wetland Areas and Environmentally Sensitive Lands, WateriWastewater Treatment, Southwest Florida Water Management District -Wells, Cypress Bayheads, Wetland Areas, Altering Watercourses. Army Corps of Engineers -Seawalls, Docks, Navigable Waterways. Department of Health & Rehabilitative Services/Environmental Health Unit -Wells, Wastewater Treatment, Septic Tanks. US Environmental Protection Agency -Asbestos abatement. Federal Aviation Authority -Runways. I understand that the following restrictions apply to the use of fill: Use of fill is not allowed in Flood Zone "V" unless expressly permitted. If the fill material is to be used in Flood Zone "A", it is understood that a drainage plan addressing a "compensating volume" will be submitted at time of permitting which is prepared by a professional engineer licensed by the State of Florida. If the fill material is to be used in Flood Zone "A" in connection with a permitted building using stem wall construction, I certify that fill will be used only to fill the area within the stem wall. If fill material is to be used in any area, I certify that use of such fill will not adversely affect adjacent properties. If use of fill is found to adversely affect adjacent properties, the owner may be cited for violating the conditions of the building permit issued under the attached permit application, for lots less than one (1) acre which are elevated by fill, an engineered drainage plan is required. If I am the AGENT FOR THE OWNER, I promise in good faith to inform the owner of the permitting conditions set forth in this affidavit prior to commencing construction. I understand that a separate permit may be required for electrical work, plumbing, signs, wells, pools, air conditioning, gas, or other installations not specifically included in the application. A permit issued shall be construed to be a license to proceed with the work and not as authority to violate, cancel, alter, or set aside any provisions of the technical codes, nor shall issuance of a permit prevent the Building Official from thereafter requiring a correction of errors In plans, construction or violations of any codes. Every permit issued shall become invalid unless the work authorized by such permit is commenced within six months of permit issuance, or if work authorized by the permit is suspended or abandoned for a period of six (6) months after the time the work is commenced. An extension may be requested, in writing, from the Building Official for a period not to exceed ninety (90) days and will demonstrate justifiable cause for the extension. If work ceases for ninety (90) consecutive days, the job is considered abandoned. WARNING TO OWNER: YOUR FAILURE TO RECORD A NOTICE OF COMMENCEMENT MAY RESULT IN YOUR PAYING TWICE FOR IMPROVEMENTS TO YOUR PROPERTY. IF YOU INTEND TO OBTAIN FINANCING, CONSULT WITH YQU R� LENDEE QR AN ATTORNEY BEEORE RECO DOFF ING YOUR NOTICE OF QQMMEt4QEMF.NT, FLORIDA JURAT (F S 117.03) , a _ r OWNER OR AGENT CONTRACTOR Subscribed and sworn to (or affirmed) before me this Subscribed and sworn to (or affirmed) before me this 8/29/22 by Ronnie Padgett 8/29/22_by Ronnie Chapel Who is/are personally known to me or has/have produced Who is/are personally known tor me or has/have produced as identification. as Identification. __—--�-�.- __Notary Public Commission No. Name of Notary typed. printed or stamped KT'AP L CHAPELy Pliblk , State of Florida mmusion k HH 056731 mm. Expires Oct 25, 2024 <f" l Notary Public IX Commission No. Name of Notary typed; printed or stamped 1LCHAPEL Notary Patolc - State of Roxida _ CommigionN Hill 056731 ,,,a„r r MY omm. 5xpt*es Oct 25, 2024 Homeowner Name: Andres Parra Spouse or Co -Owner Name: N/A Address: 35996 Morse Willow Ct City: Zephyrhills j State: FL Zip: 33541 Phone:8137702246 Email: andybajo@gmail.com Address: 35996 Morse Willow Ct City: Zephyrhills i State: FL I Zip: 33541 PV System Size: 10.67 kW Estimated 1st Year Production: 15,847 kWh This Home Improvement Contract ("Agreement") is entered into on 8/7/2022 ("Agreement Date") by ADT Solar, LLC (f/k/a Marc Jones Construction, LLC and Sunpro), ("ADT Solar," "us" or "we") and the customer(s) listed above ("Customer" or "you") (ADT Solar and the Customer may be referred to together as the "Parties") for the sale and installation of the photovoltaic solar system ("PV System") described below, and if applicable, energy storage device ('Battery"), (collectively, the "System") at the Installation Location listed above ("Property") upon the terms and conditions set forth in this Agreement, including attachments, all of which are incorporated into this Agreement. You are entitled to a completed copy of this Agreement signed by both you and ADT Solar before any work begins. The Agreement Date above is the date on which the last party signed this Agreement. Please read the entire Agreement and ask any questions you may have. 1, CONTRACT PRICE The contract price (the "Contract Price") is $52,280, consisting of $52,280 for your PV System and any Additional Work as defined below, N/A for your Battery, N/A for your re -roofing and NIA for your insulation, including sales tax, if applicable. The Contract Price is subject to any change orders agreed to in writing by both you and ADT Solar. No federal or state incentives, rebates, or tax credits were used to determine the Contract Price. 2. SCOPE OF WORK 2.1. Description of the System and Estimated Description of Significant Materials to be Used and Equipment to be Installed (the "Materials"): ADT Solar Contract V12.22.21 - ADT Solar, LLC (f/k/a Marc Jones Constriction, LLC and Sunpro) - License # CVC57068/373057, 4492-4494-4496 Eagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 DocuSign Envelope ID: crpn23co-po/9-47ec-u24e-xF44e2ec41Fa W-D Note This design is subject W redesigns due to unforeseen obsuocdnns, size restrictions, or other reasons. Any change to Re -Roofing: If you have selected to include re -roofing as part of this project, the Scope of Work will include the following - Re -roof entire roof, remove and haul away existing roof materials. See Roofing Addendum for details, terms, & conditions. Insulation: If you have selected to include insulation as part of this project, the Scope o Work will include the following - Adding blown -in fiberglass insulation to an aggregate tota of 13.25 inches (R-38 equivalent) which may include existing insulation levels. Ventilatio baffles will be installed as needed to maintain airflow. See Energypro Premiere Hom Energy Efficiency Upgrade Addendum for details, terms, & conditions. I 2.2, Work to be Performed & Standard Components Our work (the "Work") under this Agreement: design the Svstenn, secure basic building and electrical permits as needed ("Permits"), install the System on the Property, perform any Additional Work listed be|ovv, cleanup and remove debris and materials, complete and submit utility interconnection documents, coordinate bui|ding, e|ectrica|, and utility inspections required for operation of the System. No other work is included unless expressly stated elsewhere in this Agreement. Standard components ("Components") used in the Work include a production monitor, racking and mounting components, wiring, and conduit. AoTSolar Contract v1z.2zz/ AoTSolar, uc(f/k/amarc]onesConstruction, LLcand sunpro) uo,no,#cvcs/oa8o73os7, 44sz'44e444esEagle Falls Place, Tampa, pILssa19,o66-sne'zua5;Corporate Offices located atlzoworthparxBlvd, Covington, LA7u*aa 2.3. Additional Work: Additional materials and extra work required before we can begin installing your � System, and that vvewill perform for a fee' which is included in the Contract Price ("Additional Work"): I4. Additional materials and extra work required to prepare your Property for the System, and which \qu must complete at your expense prior to us beginning our Work ("Customer � Preparadons''): 3.1. This Agreement MIS O IS NOT contingent on you obtaining approval for financing by a third -party � lender, 3.2. If you are paying a portion of the Contract Price in cash and financing the remainder, $ N/A of the Contract Price vvi|| b� paid in cash' and � N/A will be financed through a third party lender. The Contract Price only includes the amount we charge for the System and theVVork.|fyouobtainfinancingfrornathirdpartV.youragreernentvvithyour|endervvi||deterrninethe total amount you owe to them and your payment schedule, and may include interest' fees' finance charges, A[H fees, U[[ removal and refi|inghces. or other charges. This Agreement does not contain the �terms ofyour financing agreement with your lender. If both Parties agree to ADT Solar performing Work, you will be responsible for payment of the Contract Price and your other obligations in this Agreement even if you do not secure financing. You are not required to use any particular lender to finance any or all of the Contract Price. ADTSo|ar is not affiliated with any lender and does not arrange or broker loans, If you choose to finance the Contract Price, carefully read any agreements and disclosure forms provided by your lender, If you have any questions about your financing agreement, contact your lender before signing contract. 33. If you are purchasing the System with cash' AOTSo|ar requires a down payment and �progress payments according tothe schedule below. Deposit(3O%): $ N/A Due upon signing ofthis Agreement � 1s'Installment (60%): $ 0/A ' Due otthe commencement ofinstallation �Final Payment (1 096): $ N/A Due upon completion of installation and passing of utility and/or local authority inspection, as applicable, but before interconnecting with yqur utility AoTSolar Contract 22,21 xoTSolar, uc(fm/amo,cJoncsConstruction, ucand sunpro) License # 44ez'44y4*m*Eagle Falls Place, Tampa, pIL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 DocuSign Envelope ID: cppB23co-ro79-47ec-u24e'xp44E29c41pa Z:1� C.,KU� Late Payment: |fADT Solar does not receive any Ufthe above payments within ten (10)days Uftheir due date, ADT Solar may charge you a late fee equal to the lesser of (i) one -and -a -half percent (1.596) per month on the amount past due, or(ii)the nnaxirnurn amount permitted under applicable law. This late fee is not an interest charge, finance charge, time -price differential, or other charge of a similar nature. 34. You acknowledge and agree that you are responsible for paying any applicable personal property oradvalorem taxes onyour System. 4. INSTALLATION TIMELINE 4.1ADT Solar will install the System within a reasonable amount of time after you sign this Agreement. We will schedule the installation of your System at a mutually agreeable time and date. 4.2. Approximate Start Date: 30-60 days from the Agreement Date. 43� 30-120 days from the Agreement Date subject to permissible delays as defined inthis Agreement. 4.4. The above Installation Timeline is an estimate and may be adjusted as provided in this Agreement, including for delays due to late payments, Customer Preparations, undisclosed, unforeseen' subsequently arising conditions, additional work required to make the Property suitable for the System, or delays caused by local permitting authorities, homeowners' associadons, orother third parties. ADT Solar will be deemed to have started work under this Agreement on the date the first Permit is applied for. After your System installation is cornp|ctc' additional time will be required for your utility to approve and connect your System to the electrical grid. Additional terms and conditions are contained in Attachment 1, and warranties are contained in Attachment 2. THIS SECTION GOVERNS ANY DISPUTE BETWEEN YOU AND ADT SOLAR. PLEASE READ IT CAREFULLY. 6.1. Good Faith Efforts. The Parties agree to make a good faith effort to resolve any dispute informally. If you have any conccrns, please contact ADT So|ar's customer service department at 1'866-508-1890 or �jupCo coID with a detailed statement of your concern. U the Parties cannot reach 8 resolution within 45 days after you notify ADT Solar of the dispute, either party may commence a formal proceeding pursuant to the process detailed below. For any prnperty, insta||adon, or performance concerns' or to perform any work as may be required by applicable |avv' you must allow us access to inspect the System and, to the extent helpful, the Property or any other property, data, information, or materials related tothe matter. 6.2. If the Pa/ties are unable to resolve a dispute informally, you and ADT Solar agree that any dispute arising out of or relating to any aspect of the relationship between you and ADT Solar will be resolved exclusively by arbitration except as specifically provided below. The arbitration, including the selection of the arbitrator, will be administered by the American Arbitration Association under its Construction Industry Arbitration Rules and Mediation Procedures, as supplemented bvthe Consumer Due Process Protocol (collectively, the "AAA Ru|es^), rather than in o court before a]udge orjury. ADT Solar Contract vla.zz.z1 ADT solar, uc(f/k/amarc]vnesConstruction, ucand Suopm) ucense#cvcs7Oaa/37sou'44sz'*m4-44asEagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 DocuSign Envelope ID: CFFB23CD-FD79-47BC-B24E-AF44E29C41 FB The location of the arbitration shall be the AAA office closest to the Property unless otherwise agreed to by the Parties, and the arbitration shall be administered by a single neutral arbitrator. The Parties may pursue all claims and remedies available under this Agreement in the arbitration. This agreement to arbitrate all disputes includes claims arising before this Agreement, such as claims related to statements about our products and services. You and ADT Solar grant the arbitrator the exclusive authority to resolve any dispute related to the interpretation, applicability, or enforceability of these terms or formation of this Agreement, including the arbitrability of any dispute and any claim that all or any part of these terms are void or voidable. The arbitrator has authority to allocate all or part of the costs of the arbitration, including the fees of the arbitrator, filings fees, expert witness fees, costs, expenses, and attorneys' fees to the prevailing party. Attorneys' fees awarded to ADT Solar for collection of any amounts due shall not exceed 20% of the amounts awarded to ADT Solar. The arbitrator's decision will be final and may be entered and enforced in any court having jurisdiction. 6.3. The arbitrator shall have the authority to award any legal or equitable relief that a court could order or grant under this Agreement. HOWEVER, THE ARBITRATOR WILL NOT HAVE AUTHORITY TO MAKE ANY RULING OR AWARD APPLICABLE TO ANY CLAIMANT OTHER THAN YOU OR ANY TRANSACTION OTHER THAN YOURS. ADT SOLAR AND YOU FURTHER AGREE THAT ALL CLAIMS AND DISPUTES WILL BE BROUGHT ONLY ON AN INDIVIDUAL BASIS, AND THE PARTIES WAIVE THE RIGHT TO BRING OR PARTICIPATE IN A CLASS ACTION, PRIVATE ATTORNEY GENERAL, OR REPRESENTATIVE ACTION ("CLASS ACTION WAIVER"). THE ARBITRATOR HAS NO AUTHORITY TO CONSIDER OR RESOLVE ANY CLAIM OR DISPUTE, OR ISSUE ANY RELIEF ON A CLASS, COLLECTIVE, OR REPRESENTATIVE BASIS, UNLESS THE ARBITRATOR OBTAINS EXPRESS CONSENT FROM ALL PARTIES. YOU MAY ALSO BRING INDIVIDUAL DISPUTES IN SMALL CLAIMS COURT. NOTWITHSTANDING THIS PROVISION, IF A COURT OF COMPETENT JURISDICTION FINALLY DETERMINES THE CLASS ACTION WAIVER TO BE INVALID, OR UNENFORCEABLE, THEN YOU AND ADT SOLAR AGREE THAT SUCH WAIVER SHALL NOT BE SEVERED AND THAT THIS ARBITRATION AGREEMENT SHALL BE VOID IN ITS ENTIRETY WITHOUT EFFECT ON THE REMAINDER OF THIS AGREEMENT. 6.4. YOU AND ADT SOLAR AGREE THAT THIS AGREEMENT TO ARBITRATE DOES NOT APPLY TO ANY CLAIM WHERE THE AMOUNT IN CONTROVERSY IS LESS THAN THE JURISDICTIONAL LIMIT OF THE SMALL CLAIMS COURT IN THE JURISDICTION WHERE YOU RESIDE, PROVIDED, HOWEVER, THAT YOU AND ADT SOLAR AGREE THAT ANY SUCH CLAIMS MAY BE BROUGHT ONLY ON AN INDIVIDUAL BASIS AND NOT AS A CLASS ACTION. 6.5. YOU HEREBY ACKNOWLEDGE THAT YOU ARE VOLUNTARILT AGREEING TO ARBITRATE ArIVT ARD All]" DISPUTES ARISING OUT OF OR RELATING TO THIS AGREEMENT, YOU ARE WAIVING YOUR RIGHT TO BRING AN ACTION IN COURT OTHER THAN CLAIMS BROUGHT IN SMALL CLAIMS COURT, AND YOU ARE AGREEING TO ARBITRATE ON AN INDIVIDUAL BASIS AND NOT AS PART OF A CLASS. You can obtain more information about arbitration and the AAA Rules online at www,adr,org or or by calling 1-800-778-7879 or any AAA office. Signature. DocuSigned by: Customer: / -Accepted Spouse/CO-OWn * Acn744s9.. -Accepted 7. Addresses for Notices: Any notices provided to Customer under this Agreement shall be sent to the Mailing Address or the Customer's email address indicated at the top of this Agreement. Any notices to ADT Solar (flkla Marc Jones Construction, LLC and Sunpro) under this Agreement shall be sent to: ADT Solar, LLC, AT1-N: Customer Service, 128 Northpark Blvd, Covington, LA 70433. ADT Solar Contract V12.22.21 - ADT Solar, LLC (f/kla Marc Jones Construction, LLC and Sunpro) - License # CVC570681373057, 4492-4494-4496 Eagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 DocuSign Envelope ID: CFFB23CD-FD79-47BC-B24E-AF44E29C41FB , WA�C a (, I ~gl-;I "` 8. Severability: In case any one or more of the provisions, or portions of a provision contained in this Agreement or any other documents referred to herein or executed in connection with this Agreement or otherwise, should be invalid, illegal, or unenforceable in any respect, the validity, legality, and enforceability of the remaining provisions contained herein and therein shall not in any way be affected thereby. It is the Parties' intention that if any such provision, or portion thereof, is held to be illegal, invalid, or unenforceable, this Agreement shall be modified to affect the original intent of the Parties as closely as possible to be legal, valid, and enforceable. 9.1. ADT Solar provides you an industry -leading Power Production Guarantee to ensure your PV System performs as expected. 9.2. Based on the Site Design above, your PV System is estimated to produce 15,847 kWh (the "Estimated 1 st Year Production") in the first 12 months following the date on which your System is fully activated (the "Operational Date") and is estimated to produce 380,876 kWh over the first 25 years following the Operational Date (the "PPG Term") according to the following schedule: Estimated Annual Estimated Annual PPG Year [ PPG Year Production Production Year 1 ' 15,847 kWh I Year 14 1 5,1 81 kWh t Year 2 1 15,795 kWh Year 15 ! 151131 kWh Year 3 I 15,743 kWh Year 16 i 15,081 kWh ` 1 Year 4 15,691 kWh I Year 17 15,031 kWh 1 Year 5 i i 15,639 kWh I Year 18 k 14,982 kWh ' Year 6 15,588 kWh Year 19 14,932 kWh Year 7 115,536 kWh Year 20 14,883 kWh Year 8 15,485 kWh Year 21 14,834 kWh ( 3 j Year 9 15,434 kWh I Year 22 14,785 kWh I Year 10 15,383 kWh Year 23 ! 14,736 kWh € Year 11 15,332 kWh Year 24 a 14,687 kWh ------- fi_.---- Year 12 15,282 kWh I Year 25 14,639 kWh 3 Year 13! 15,231 kWh [ _ _ _...._ . .___. -_- _ __ _ __.__ ___ .. -------- ADT Solar Contract V12.22.21 - ADT Solar, LLC (flkla Marc Jones Construction, LLC and Sunpro)- License # CVC57068I373057, 4492-4494-4496 Eagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 DocuSign Envelope ID: CFFB23CD-FD79-47BC-B24E-AF44E29C41 FB 1 � ;k I U I 9.3. For each "PPG Year," shown above, ADT Solar guarantees that the PV System will generate at least 95% of the Estimated Annual Production for that PPG Year (the "Guaranteed Annual Production"). This schedule assumes a degradation rate of 0.33% per year. 9.4. If the PV System does not produce the Guaranteed Annual Production for any PPG Year, and you notify us of your request for a review within 1 year of the end of that PPG Year, ADT Solar will pay you $0.10 per kWh ("PPG Rate") of the difference between your System's Actual Production and the Guaranteed Annual Production for that PPG Year. 9.5. "Actual Production" means the amount of electricity produced by your System. To calculate the Actual Production, we will use the data provided by the monitoring system installed with your System or if such data is not available, we will estimate the Actual Production by commercially reasonable methods. 9.6. For example, if your Guaranteed Annual Production for a PPG Year is 10,000 kWh, but your Actual Production for that PPG Year is only 9,000 kWh, we would multiply the difference (1,000 kWh) by your PPG Rate ($0.10/kWh), which equals $100. 9.7. Your Estimated 1 st Year Production, Guaranteed Annual Production, and this PPG are based On the Site Design above. If there are any adjustments to your Site Design pursuant to a written change order, your Estimated 1st Year Production, Guaranteed Annual Production, and this PPG shall be automatically adjusted according to the final installed System design. See Section 11 below for more details. This PPG is also subject to the additional terms and conditions contained in Attachment 2. 9.8. Overproduction. ADT Solar does not charge you for any energy your System generates in excess of the Guaranteed Annual Production, and any such overproduction will be credited against future underproduction. 10. Note About Extra Work and Change Orders: Extra Work and Change Orders become part of the Agreement once the change order is prepared in writing and signed by the Parties prior to the commencement of work covered by the new change order. The change order must describe the scope of the extra work or change, the cost to be added or subtracted from the Agreement, and the effect the order will have on the schedule of progress payments or the completion date. You may not require ADT Solar to perform extra or change order work without providing written authorization prior to the commencement of work covered by the new change order. ADT Solar's failure to comply with the requirements of this paragraph does not preclude the recovery of compensation for work performed upon legal or equitable remedies designed to prevent unjust enrichment. 1 1 . Site Designs & Revisions: The Materials, Components, Estimated 1 st Year Production, and PPG are estimates based on the preliminary Site Design of your System contained in Section 2.1 above. ADT Solar may perform additional reviews of the Site Design, including site visits to the Property to verify feasibility of the System design, You will have the opportunity to review and approve any revision to the Site Design (each revision, a "Revised Site Design"). Revised Site Designs that do not require a change order: Revised Site Designs that meet all of the following criteria will not require the Parties to execute a change order: (a) no change in the Contract Price, and (b) no change in the Materials provided or Work performed, and (c) do not result in a reduction of the Guaranteed Annual Production by more than 10%. However, in the event a Revised Site Design results in a reduced Guaranteed Annual Production and a change order is not executed along with the Revised Site Design, the PPG will not be reduced; it will remain the same as with the last approved Site Design. You will have 5 business days ADT Solar Contract V12.22.21 - ADT Solar, LLC (f/k/a Marc Jones Construction, LLC and Sunpro) - License # CVC57068/373057, 4492-4494-4496 Eagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 DocuSign Envelope ID: CFFa23co'+o79-47oo-a24e+\p44c29c41pa �)N("J I from your receipt of Revised Site Design to request any changes; otherwise you will be deemed to have approved it. We may begin installation of your System if you have given your written, deemed, or verbal approval of any Revised Site Design, including verbal approvals given on the day oforwithin 5 days prior to the installation date, Revised Site Designs that will require a cha ge order: Revised Site Designs that do not meet all of the criteria above must heaccompanied by avvritten change order, signed by both you and ADTSolar, before vvewill proceed with any further Work. The change order may result in an adjustment to the Contract Price. The Estimated 1st Year Production' Guaranteed Annual Production. and PPG will be automatically adjusted to match the Revised Site Design and change order. If you request o Revised Site Design after ADT Solar has requested, applied for, or received permits or other authorizations based on an approved or deemed approved Site Design, you will be responsible and separately invoiced for any costs associated with requests or applications for new or revised permits orother authorizations caused by the Revised Site Design. 12. Governing Law and Venue: This Agreement shall be governed by the law of the state in which the Property is located, and venue shall be the county/parish where the Property is located, except that the arbitration clause in Section 6 above shall be governed by the Federal Arbitration Act 11 Notice of Right to Cancel: You have the right to cancel this Agreement any time within 3 busines3 days after the Agreement Date or, if you are 65 years of age or older, you may cancel this Agreement within 15 business days after the Agreement Date. Please review the attached notice of cancellation forms for an explanation of your right to cancel. 14. yJoTax Advice: ADTSo|ar makes no representation about and takes no position on the tax consequences of this Agreement, the VVork, or the System. A dispute regarding the Lax implications of this Agreement or the System shall not affect the validity of the Agreement. For more information, see Attachment 5 Homeowner's Guide to the Federal Solar Tax Credit. 15� Entire Agreement: This Agreement supersedes any prior understandings' egreernents, or representations by or between the PanLies, written or oral, to the extent they related in any way to the subject matter hereof. 16. Successors: This Agreement shall be binding upon and shall inure to the benefit of the Parties and their respective successors, assigns, heirs, purchasers, and representatives. Attachment Terms &Conditions Attachment Limited Warranties and Additional Terms & Conditions for the PPG and Batteries Attachment 3 ' Notice of Cancellation Forms Attachment Legal Notices Attachment 5 Homeowner's Guide to the Federal Solar Tax Credit Attachment 6'SE|ASolar Purchase Disclosure xorsu|n/ c:nuuctv12.zzzl AoTso|ar' uc(f&m Mao]onesconstrumoo' ucand sunprn) License #cvcsmao/37aos7, 44e2'4494-44e6 eagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, Lx7o1aa DocuSign Envelope ID: CFFB23CD-FD79-47BC-B24E-AF44E29C41FB 1 g x, t NOTICE TO CUSTOMER: Do not sign this Agreement if blank. You are entitled to a copy of the Agreement at the time you sign. You, the buyer, may cancel this transaction at any time prior to midnight of the third business day (or fifteenth business day if you are 65 years of age or older) after the date of this transaction. See the attached notice of cancellation'; form for explanation of this right. Customer: Contractor: DocuBignedby: ADT Solar, LLC (f/k/a Marc Jones Construction, LLC and Signature: Sunpro) 87 EKBGD74499... DocuSigned by: Name: Andres Parra Signature: FAA 111i 3E1D91570517430... Date: 8/7/2022 Name: Michael Lemon Title: Solar Energy Specialist Date: 8/6/2022 ADT Solar, LLC ATTN: Customer Service 128 Northpark Blvd Covington, LA 70433 ADT Solar Contract: V12.22.21 - ADT Solar, LLC (f/k/a Marc Jones Construction, LLC and Sunpro) - License # CVC57068/373057, 4492-4494-4496 Eagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 DocuSign Envelope ID: CpFe23co'po7e-47ao-e2*s-ap44E29c41po The Parties agree these Terms & Conditions are incorporated into the Agreement as though they were set forth fully therein. Capitalized hsrrns not otherwise defined herein shall have the same meanings as those set forth in the Permits & Authorizations: ADTSolar will obtain any necessary basic building and electrical Permits at ADT So|ar's cost. Customer is responsible for obtaining any other permits or authorizations, including homeowners' associations and planning, zoning, architectural, or historical preservation commissions. AOT5o|ar is not responsible for any delays caused by permitting authorities, utilities, orregulators. Any deadlines, including those in the Installation Timeline, shall be automatically extended to compensate for any delays caused by permitting authorities, utilities, regulators, or other third parties not reasonably within our control. 2. Pll You are responsible for the structural integrity of the Installation Location' including structural or electrical modifications necessary to prepare your Property for the System, and including any Customer Preparations. ADT Solar is not obligated to begin or continue any Work if Customer Preparations are not complete orif Property conditions are not suitable for performing the Work. You agree that ADTSolar is not responsible for any known or unknown Property conditions. The Contract Price assumes that existing roofing materials (except to the extent that the Contract Price includes re -roofing) and structural supports will be adequate to carry the load of all equipment to be installed and work to be done under this Agreement. If any modification of roofing materials and/or reinforcement of existing structural supports is required and is not otherwise specifically stated and charged for |n the Agreement, ADTSolar will be entitled to a change order providing on increase to the Contract Price and an extension of the Installation Timeline. Roofing leaks or compromised roof decking/materials that are not identified during the design phase may become apparent during installation. If these conditions are discovered' we will notify you to discuss the issue. ADT Solar will not have any obligation to make any repairs or perform any work necessary to make the Property feasible for installation of the System unless included in the Additional Work above or as executed in a mutually agreeable change order. 3. Existing ADTSo|ar is not responsible for and bears no liability for the malfunctioning of existing electrical equipment at the Property, including but not limited to the main electrical service panel, any rne|or electrical devices' or any other fuses or similar devices. You will provide 1 1O'vo|t electrical power from the existing distribution system on the Property for hand-held portable power tools at no cost to ADT Solar. 4. Unless otherwise specifically stated inthe Agreement, the Work to be performed by ADT Solar specifically excludes installation of critter guards; roof repair or support; trenching; removal or disposal of hazardous waste not placed thereby us; removal orreplacement of rotted, rusted, or insect -infested structures; correcting errors by Customer or other contractors not under our control; tree trimming, removal, or relocation, trimming of landscape materials; structural, cosrnedc, or electrical work; and relocation or installation of vvaLer. Aas, sewer, e|ectric, or communication AorSolar Contract v/z.zz2l ^nTSolar, uc(f/k/amarc]n^esConstruction, ucand sunpro) ucenseocvc57nom37sn5r *mz'44e444msEagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 oocuSign Envelope ID: cFpBaoco'po7*4rec'e24e'xp44szsc41pB � n� n����m .�.�. 5.Solar provides you with a 25-Year Power Production Guarantee in Section 9 of the Agreement. Net savings may vary based on home location, home age and construction, system size, incentive and rebate programs, net metering policies, your changing energy consumption, utility rates, and fuel costs. Net metering and other utility or solar policies may change at any time. You are responsible for knowing and understanding the net metering, avoided cost, or other programs offered by your utility regarding excess electricity generated by your System, We design our systems to save money over the long term and to offset all or most of your current electricity consumption, and we guarantee the System's production for 25 years through the PPG. However, ADT Solar does not guarantee savings or that your utility bill will be reduced to $0.00. DS Agreed and accepted by: F9 e N/A (Customer lnitials�- 6. Customer ResDonsibilities: Customer shall take all reasonable measures to prevent overshading or other interference with the operation and production of the System, Customer must also provide a safe worksite with access to electrical power and water. Customer shall assist ADT Solar in responding to requests for information from any permit - issuing authority, any government body, or agency or as otherwise needed to perform the Work, and any requests by any third -party finance company. 7. Batteries: Any Battery incorporated into the System is intended to draw 100% of its charge from the PV System. It is not intended to discharge electricity back to the utility grid. The Battery can provide backup power only to a selected set of essential circuits and may not power your entire Property. Loads powered by the Battery, and the length of time the loads can be powered, are dependent upon the charge of the Battery at the time of a grid outage, the rnaxirnurn discharge nsU* of the inverter, and the Battery discharge settings as determined by the Customer, Customer will need to self - manage their consumption patterns and load for both back-up and self -consumption applications, om Agreed and accepted by: 5 p N/A (Customer Initials) 8. Incentives, Rebates 8.1. You may qualify for tax credits, rebates or other incentives related to your System ("Incentives") offered by federal, state, or local Rovernrnents' your utility provider. or others. ADT Solar does not own or control any Incentives related to your System, and ADT Solar makes no representation' vvarranty, or guarantee about the nature, existence, or availability of any Incentive or whether you will qualify for any Incentive. You are solely responsible for completing and submitting any paperwork or information required to obtain any Incentive, We agree to provide you with reasonable support and documentation required for you to apply for Incentives. Neither ADT Solar nor your utility make any representations or warranties concerning the tax implications ofany bill credits provided to CultUMbir. Agreed #P and accepted by: (Cu'sToTffer Initials) B. Prop.Qrty Access 9.1. You hereby grant to ADT Solar and its employees, agents, and contractors the right to reasonably access all of the Property as necessary between the hours of7:OOarn and 6:00prn. Monday through Saturday to perform the Work oraddress our rights and obligations under this Agreement. Sl In the event Customer authorizes ADT Sn|ar's access to the Property through adjacent properties for any reason, Customer is required to obtain written permission from ADT Solar zzz1 ADT Solar, uc(fm/a Marc/onesconstromon' LLcand Sunpro) ucen,e# 4492-44944496 Eagle poUs p|ace, Tampa, pLzps19,ua6-s9e3as5;Corporate Offices |ootedat 1zuNorth park a|vd'Covington, /x7o4uz DocuSign Envelope ID: cFpo23co'po79-47oc-B2*s+\p44E29c41pa Iwo, CC, I Customer cancels �hizAercennenta�erthc�- the owner(s) of the adjacent properties for daycance||aUonperiod(-r1�'d�ycance||ation such use, and Customer agrees to be solely period if you are age 65 or older), Customer for and to defend, indemnify, and agrees �o pay �o ADT Solar, as liquidated hold ADT Solar harmless from, any and all damages and no�� fee, either(a)$�'OOO or forms of liability that may arise out of or relate 1896 of the Contract Price' whichever is less, to such use. within seven (7) business days of providing ��gCustomer agrees to allow ADT Solar with notice of Customer's decision10. ADT Solar the right to monitor Customer's to terminate this Agreement. Customer agrees electricity consumption and Systemthat this amount is reasonable based on the production, and grants ADT Solar permission anticipated or actual harm caused by the to view and access such data. ADT Solar may termination, actual out-of-pocket costs also receive information about you from other incurred, the difficulties of proof of loss, and sources' such as equipment manufacturers the inconvenience or non -feasibility of and utility companies. ADT Solar will not share otherwise obtaining an adequate remedy. your data with third parties except to the Customer may not terminate this agreement, extent necessary to fulfill obligations under except as provided by Section 13 below, after this Agreement or in an anonynnized or - any Materials have been installed on the aggregated format. Property. l 1 . All materials delivered to 13. ADT Solar may, upon the Property, regardless of whether 10 days' written notice to [Vstnrner' terminate incorporated into the System, are and will~ this Agreement breach failure of Customer ' remain the property of ADT Solar until such to agree to any change order deemed by ADT time asthe Contract Price is paid infull. Title tn Solar to be necessary, failure of Customer to the System shall transfer to you after ADT pay any amount due, bankruptcy of Customer, Solar completes installation of the System and any failure by the Customer �o cooperate in you make final payment. Notwithstanding the the installation process, if Customer foregoing' after delivery of the System Preparations are not completed, or if the equipment and materials to your Property. Property Condition is not suitable to perform you bear risk of loss to the System for all the Work. Customer may terminate this causes of loss not covered by the Limited Agreement upon written notice if ADT Solar Warranty (as set forth in Attachment 2) does not commence or complete work within However, you will not bear any risk ofloss for the time periods inSection 4nfthe Agreement, damage directly resulting from ADT So|or's and Customer will be entitled to a refund of negligent actions or omissions or «vi||fu| any down payment or other payments made misconduct. ADT Solar retains all ADT Solar- towards the Work. However, Customer shall owned intellectual property rights on any of remain liable to ADT Solar for any work the equipment installed in your System performed. including,without limitation, patents ' ' 14. Re�OjedijesLU: In addition Up copyrights, trademarks, and any deLa ' to its rights in Section 13 above, and without generated by ADT So|ar's monitoring system. limiting any of ADT So|ar's other rights and 12. Liquidated Damages: Customer agrees and remedies, upon any breach by Customer, acknowledges that ADT Solar will incur costs including any failure of Customer to pay any and expenses preparing to perform the VVorh. amount due ' ADT Solar shall have the right, to designing the System, obtaining permits and the fullest extent a||ovved by law, to: (a) pursue approvals, and acquiring Materials and a stop work order at the Property; (b) stop any Components after this Agreement is signed, If more work from being done at the Property ADT Solar Contract v12,zzzl ADT Solar, uc(f&mma/c]onesConstruction, ucand »unpm) ucense#cvcrmano7zns7'44sz'44s4*mssagleFalls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 DoeuSign Envelope ID: CFFB23CD-FD79-47BC-B24E-AF44E29C41FB w5a1, until the breach is cured and a bond is posted by the Customer for any amounts payable under this Agreement; (c) recover all amounts due under this Agreement for services provided through the date of termination including interest at the rate of 1.5% per month or the highest rate allowed by applicable law, whichever is less; (d) require you to return the System at your expense and/or- make the Property available to us to remove the System; (e) disconnect, turn off, or take back the System by legal process or self- help (if legally available), provided ADT Solar does not disturb the peace or violate the law (you agree that ADT Solar will have access to your Property and permission to enter your Property in order to disable and/or remove the System until such time as ADT Solar is paid in full and title to the System passes to you); (f) reportsuch non -operational status of the System to your utility, informing them that you are no longer net metering; (g) charge you a reasonable fee for reconnecting the System to your utility or turning your System back on after it is disconnected or turned off; and (h) any other legal remedies including, without limitation, mechanic's liens. 15. Lien Releases: If a lien should be placed on your Property by ADT Solar, upon satisfactory payment for any portion of the work performed, ADT Solar shall, prior to any further payment being made by Customer, furnish to Customer a full and unconditional release from any potential lien claimant claim or mechanics' lien authorized pursuant to relevant law for that portion of the work for which payment has been made by Customer. 16. Insurance: ADT Solar carries commercial general liability and workers' compensation insurance for all employees. 17. Indemnification: Each Party agrees to indemnify, defend, and hold harmless the other Party and its employees, officers, directors, agents, and assigns from any and all third -party claims, actions, costs, expenses (including reasonable attorneys' fees and expenses), damages, liabilities, penalties, losses, obligations, demands, and liens of any kind arising out of or relating to its breach of its obligations under this Agreement. Neither Party will be required to indemnify the other Party for such other Party's own negligence, willful misconduct, or fraud. 18. Exercise of Reasonable Care: ADT Solar will exercise reasonable care not to damage your Property during installation of the System. In the event of damage to the Property due to ADT Solar's installation of the System, ADT Solar agrees to make reasonable efforts to repair such damage at ADT Solar's cost. 19. Force Majeure: Except with respect to any payment obligations hereunder, both Parties shall be excused for delay in the performance of any obligations hereunder to the extent that such delay is the result of or attributed to a force majeure event ("Force Majeure Event"). For purposes of this Agreement, a Force Majeure Event means any cause beyond the affected Party's reasonable control including but not limited to acts of God such as storms, fires, floods, lightning and earthquakes, sabotage or destruction by a third party of a System, war, riot, acts of a public enemy or other civil disturbance, or a strike, walkout, lockout or other significant labor dispute, interruptions in delivery of supply of parts or raw materials, the issuance of any new utility requirements, trade association, or government laws. 20. Limitation of Liability_ 20.1. TO THE EXTENT ALLOWED BY APPLICABLE LAW, EACH PARTY'S LIABILITY TO THE OTHER UNDER THIS AGREEMENT SHALL BE LIMITED TO DIRECT, ACTUAL DAMAGES ONLY. BOTH PARTIES AGREE THAT IN NO EVENT SHALL EITHER PARTY BE LIABLE TO THE OTHER FOR CONSEQUENTIAL, INCIDENTAL, PUNITIVE, EXEMPLARY, SPECIAL OR INDIRECT DAMAGES, INCLUDING WITHOUT LIMITATION (a) PHYSICAL OR MENTAL PAIN AND SUFFERING OR EMOTIONAL DISTRESS DAMAGES; (b) ADT Solar Contract V12.22.21 - ADT Solar, LLC (f/k/a Marc Jones Construction, LLC and Sunpro) - License # CVC57068/373057, 4492-4494-4496 Eagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 North park Blvd, Covington, LA 70433 DocuSign Envelope ID: CFF623CD-FD79-47BC-B24E-AF44E29C41 FB 07 r e 1 I � ia IF COSTS OF TEMPORARY SHELTER, TRANSPORTATION, FOOD, MOVING, STORAGE, OR SIMILAR INCIDENTAL DAMAGES OR EXPENSES; (c) LOSS OF USE, LOSS OF OPPORTUNITY, LOSS OF FAIR MARKET VALUE, LOSS OF RENTAL VALUE, LOSS OF FINANCING, OR SIMILAR LOSS OF ECONOMIC OPPORTUNITY; OR (d) LOSS OF PROFITS (OTHER THAN THOSE THAT WOULD HAVE OTHERWISE RESULTED FROM THIS AGREEMENT) OR LOSS OF BUSINESS OPPORTUNITY OR REPUTATION. Some states do not allow the exclusion or limitation of incidental or consequential damages, so the above limitation or exclusion may not apply to you. 20.2. Except for damages arising out of misappropriation of either Party's intellectual property, and only to the greatest extent allowed by law, in no event will either Party's liability under this Agreement or in connection with the System, exceed the Contract Price, including, without limitation, damages to your Property during the installation of the System or resulting from the operation of the System. Customer agrees to provide ADT Solar with written notice of any claims arising out of this Agreement and/or the System prior to making final payment and any claims not made at or before such time will be deemed waived by Customer upon making final payment. 21. Limitations of Use 21.1. YOUR SYSTEM, WITHOUT THE ADDITION OF AN INCORPORATED BATTERY DESIGNED FOR SUCH USE, WILL NOT OPERATE DURING A UTILITY GRID OUTAGE, AND WILL SHUT DOWN UNDER THIS CIRCUMSTANCE. Ds Agreed and accepted by: _ Q N/A (Customer Initials) 21.2. YOUR SYSTEM, EVEN WITH A BATTERY INCLUDED, IS NOT INTENDED FOR USE AS PRIMARY OR BACK-UP POWER SOURCE FOR CRITICAL CARE INCLUDING LIFE-SUPPORT, OTHER MEDICAL EQUIPMENT, OR ANY OTHER USE WHERE PRODUCT FAILURE COULD LEAD TO INJURY TO PERSONS OR LOSS OF LIFE OR CATASTROPHIC DAMAGE. ADT SOLAR DISCLAIMS ANY AND ALL LIABILITY ARISING OUT OF YOUR USE OF THE SYSTEM FOR THESE PURPOSES AND DISCLAIMS ANY AND ALL LIABILITY ARISING OUT OF ADT SOLAR'S SERVICE OR REFUSAL TO SERVICE YOUR SYSTEM IN SUCH CIRCUMSTANCES. 22. Photography- You agree that ADT Solar has the right to obtain photographic images of your System and your home, and to use such photographic images for internal and quality control purposes. ADT Solar may use photographic images of your System or your home in its marketing and promotional materials. Customer Signature: F// DocuSigned ky: N/ 8731E8CBCD74499. ADT Solar Contract V12.22.21 - ADT Solar, LLC (f/k/a Marc Jones Construction, LLC and Sunpro) - License # CVC57068/373057, 4492-4494-4496 Eagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 Iwo I !, _'. 1,11 Limited Warranties and Additional Terms &K-ond^t~ons for the Power Production Guarantee /PPG\and | Batteries The Parties agree this Attachment 2 is incorporated into the Agreement as though it was set forth fully therein. Capitalized terms not otherwise defined herein shall have the same meanings as those set forth in the Agreement. ADT Solar may assign or transfer these Limited Warranties to a third party. This warranty gives you specific legal rights, and you may also have other rights which vary from state to state. THE FOLLOWING DESCRIBES THE TERMS AND CONDITIONS OF THE LIMITED WARRANTIES COVERING THE SYSTEM INSTALLED AT YOUR PROPERTY PURSUANT TO THE AGREEMENT ENTERED INTO BY AND BETWEEN YOU AND ADT Limitation of Warranty: THE WARRANTIES SET FORTH HEREIN SHALL CONSTITUTE THE ONLY WARRANTIES APPLICABLE TO THE AGREEMENT, THE SYSTEM, AND THE WORK. ADT SOLAR DISCLAIMS, AND YOU WAIVE, ALL OTHER WARRANTIES OR GUARANTEES, EXPRESS OR IMPLIED, THAT ARE NOT SET FORTH EXPRESSLY HEREIN, INCLUDING WITHOUT LIMITATION AS TO THE MERCHANTABILITY, FITNESS FOR ANY PARTICULAR OR ORDINARY PURPOSE, CONDITION, DESIGN, CAPACITY, SUITABILITY OR PERFORMANCE OF THE SYSTEM OR ITS Some states do not allow limitations on how long an implied warranty lasts, so the above limitation may not apply to you. Our Limited Warranties Subject to certain limitations stated below, we provide the following limited warranties (collectively, the "Limited Warranties") for your System and our Work: 25-Year Limited Workmanshiip� Marranty ("Workmanship Warranty"): ADT Solar warrants that the System | be installed in a good and workmanlike manner according to the reasonable standards of care and diligence generally practiced by solar installation companies when installing residential photovoltaic systems of similar size and type as the System in thegeographic region where the Property is located and pursuant to the manufacturer's instruction. applicable |avv' and requirements ofthe local permitting and inspection authorities and your utility. 10-Year Limited Roof Leak Warranty ("Roof Leak Warrall If you are incompliance with all your obligations under the Agreement, for period of 10 years beginning on the Operational Date, ADT Solar warrants your roof against water infiltration at each roofing penetration made byADTSolar in connection with the installation of the System and the surrounding area within a 3-inch radius of each such penetration (collectively, the "Covered Roof Areas"). � Manufacturer's Warranties for Products and Materials ("Manufacturer's Warranties"): The major Materials and Components nfyour System - panels, inverters' racking and mounting system, and rnonitohngdevice- all have Manufacturer's Warranties. Following installation ofthe System, ADTSolar will provide you with copies ofall relevant ADT Solar Contract V12.22.21 - ADT Solar, LLC J/k/a MarcJones Construction, LLC and Sunpro) -License# CVC57068/373057, 4492-4494-4496 Eagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 DocuSign Envelope ID: oppo23co-po79-47ao-e24e'Ap44E2eo*/pu � o i a r UPON RECEIPT OF PAYMENT IN FULL UNDER THIS AGREEMENT, ALL WARRANTIES THAT ARE PROVIDED BY MANUFACTURERS OF EQUIPMENT USED IN THE SYSTEM WILL BE TRANSFERRED DIRECTLY TO YOU. YOU UNDERSTAND THAT ADT SOLAR HAS NO RESPONSIBILITY WITH RESPECT TO SUCH WARRANTIES OTHER THAN TO TRANSFER THEM Exclusions from Warranties The Limited Warranties and the PPG do not apply to a e. repair, replacement, loss or corrective action required due toany ofthe following: N/& (Customer Initials) Any actions performed or materials used or installed by anyone other than ADTSo|ar or its approved service providers, including repairs, alterations, movement, or modification to the System or any portion of the System for any reason; 2. Destruction ordamage tothe System, including any Battery' or its ability to safely or effectively produce or store power that is not caused by AOTSo|ar or its approved service providers in the course of performing its obligations under this Agreement (for example, any damage that is the result ofnatural disasters, vegetation, tree limbs, or golf ball strikes), or the actions of persons or parties not within our reasonable control; 3. Your negligence orfailure to properly operate or maintain the System ortotake appropriate action to minimize any damage as soon as reasonably practicable, including any failure to clean the System as needed and according to manufacturer's instructions; 4. Ordinary wear and tear, including cosmetic defects; 5. Power or voltage surges caused by someone other than ADT Solar or its service providers, including a grid event; 5. Theft, removal, or disabling of the System or the production monitoring device; 7. Damage resulting from rno|d' fungus' and other organic pathogens; 8. Shrinking nrcracking ofgrout and caulking; 8, Fading of paints and finishes exposed to sunlight; in particular, ADT Solar is not responsible for ensuring repaired or replaced shingles or other roofing materials match other sections of the roof that have become discolored orfaded; 10. Pre-existing and/or underlying failures ofthe roof; 11. Earthquake, fire, flood, hail, soot, salt damage, or other weather conditions or other acts of God; 12. Any damages or losses covered by your homeowner's insurance policy or any other insurance policy; 13. Damages resulting from condition ofthe Property; 14. Damage from pests orrodents; 15� Snow covering orasnow load damaging the System; 15. Systems with the type orserial nurnber(s)akered. rernoved, or illegible; xoTSolar Contract v12.zza1 AoTSolar, uc(f/k/ama,c!onesConstruction, ucand sunpm) ucense# *m2-44y4449*Eagle Falls Place, Tampa, FL 336197 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, !-A7n4as 17. Any otherwise covered claims of which you do not notify ADT Solar within 30 days of your discovery of the basis for the claim, Circumstances that will Void the Limited Warranties The Limited Warranties and the PPG provided in this Agreement will be voided entirely by any of the following: 1 , Your gross negligence or your intentional damage to the System; 2. Your breach of or failure to perform your obligations under the Agreement and/or the Limited Warranties, including but not limited to any failure to report system damage or failure, not cooperating with us or any third party to assist in the assessment of or repairs to the System, or failure to properly operate the System in accordance with the owner's manual or manufacturer's instructions; 3. Any actual or attempted installation, repair, alteration, replacement, movement, change, or modification to the System made by anyone other than ADT Solar or its approved service providers, or without ADT Solar's prior written consent; 4. Improper use or operation; 5. Any violation of a Manufacturer's Warranty; 6. Energizing your System without utility's prior written consent to operate and ADT Solar's express, written Additional IpPG Terms and Conditions In addition to the above, the PPG requires that you have and maintain active electrical service and internet connection. If at any time you fail to provide electricity or internet connection, or ADT Solar is unable to monitor the System remotely for any reason, Actual Production during that period will be estimated by ADT Solar using reasonable means. Actual Production will be adjusted to include electricity that ADT Solar estimates would have been produced during any time periods when the System is shut down or producing less power due to a transmission grid failure, at your request, or due to your failure to perform any of your obligations under the Agreement. You agree to notify ADT Solar immediately upon your discovery that the electricity at your Property or your internet connection has not or will not be available for more than 48 hours. IF THE PROPERTY DOES NOT HAVE AND MAINTAIN ACTIVE ELECTRICAL SERVICE OR INTERNET CONNECTION FOR A PERIOD LONGER THAN THIRTY (30) DAYS, THE PPG WILL AUTOMATICALLY The PPG 1Shading installed or shading from structures built or modified after the System was installed; 2. Shading from h |s covering the System, including but not limited to snow coverage, dust, debris, leaves; 3. Accidents, | i damage to the System (for example, golf ball strikes or fallen limbs); 4. Grid failures, grid events, or other utility interruptions that disable or interfere withthe normal operation ofthe S. issues' reporting issues' or any other condition for which you do not promptly give us notice in writing within 30 days of the date you first become or reasonably should have become aware ofthe circumstances giving rise tosuch issues; ADT Solar22.21 AoTSolar, L/c(f&mmarc]onesConstruction, ucand svnpro) License #cvcs7uau/37zos7.**s2-«4s4*msEagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 DocuSign Envelope ID: orFo23cu-po79-47ac;o24s-x+44s2ec41pe 6. Any nfthe items included inthe statement ofexclusions from the Limited Warranties orcircumstances that will void the Limited Warranties above. Any actual or attempted installation, repair, alteration, replacement, movement, change, ormodification tothe System made by anyone other than ADT Solar or its approved service providers' orwithout ADT 5o|ar's prior written consent will automatically void the PPG. Having an incorporated Battery as part of your System will not affect the PPG, A Battery incorporated into the System is designed to draw its charge from the PVSvs1ern' simply storing the energy produced by the PVSvs{ern for discharge according toits programming. If the System performs better than the PPG (i.e., the SvsLern's Actual Production is greater than the Guaranteed Annual Production during the PPG Term) then this surplus energy is yours at no additional cost, If you sell your hurne. the PPG and the Limited Warranties (except, as applicable, any Manufacturer's Warranties with different provisions) are transferrable to the new owner if you provide written notice to ADT Solar within 30 days of the sale of the Property, pay a $250 transfer fee, and notify us of the date of the sale and the new owner's name and contact information. Transfer shall not be effective until the new owner signs a written acknowledgment accepting all of the terms and conditions of this Agreement. If you have financed your System, contact your lender for any adcfttD"al restrictions. (Customer Initials) To ask a question regarding the Limited Warranties, the PPG, or this Agreement, you may call ADT Solar at 1 833.409.10O7. To submit a claim or provide any other notice under the Limited Warranties, the PPG, or a notice to transfer, you must send us the request inwriting, certified or registered first-class mail, post prepaid, with a return receipt requested, or nationally recognized courier service requiring signature for receipt, to the following address: ADT Solar, LL[ ATTN:Warranty Claims &Transfers 128NorthparkBlvd Covington, LA70433 To notify you regarding a Limited Warranty, the PPG. or this Agreement, ADT Solar may send you a notice in vvhdng in the manner described above, or to the email or mailing address provided in the Agreement or any subsequent contact information that you provide to us. The Parties agree that any ernai|ed document shall be deemed an original document. ADT Solar Contract vl2.z2.z1 ADT Solar, uc(fmmma/c]onesConstruction, LLcand sunprn) uo,osamcvcs7osoo7aos7 4492-11ef*maEagle Falls Place, Tampa, pLsaale.oaassy's6a5;Corporate Offices located at/zowurmpark Blvd, Covington, LA7n4z3 DocuSign Envelope ID: CFF623CD-FD79-47BC-B24E-AF44E29C41 FB u �k r If ADT Solar receives a claim under a Limited Warranty or PPG from you, ADT Solar will review your claim and notify you within 1!5 business days whether your claim is covered. If ADT Solar cannot make this determination without inspecting the System, ADT Solar will send an employee, contractor, or agent to your Property within 15 business days of the date ADT Solar receives your claim, and ADT Solar will then notify you within 10 business days of the visit as to whether your claim is covered by a Limited Warranty or the PPG. If your claim is covered by a Limited Warranty or the PPG, ADT Solar to either (1) pay you the required amounts under the PPG, or (2) make the repair or replacement under the Limited Warranty within a reasonable period of time, at no cost to you. ADT Solar may use new or reconditioned parts to make repairs. The warranty period will not be extended, nor will a new warranty period begin, upon any repair or replacement conducted under this warranty. ADT Solar will use commercially reasonable efforts to replace parts with the same type of equipment but may substitute materials or types of equipment if necessary. Any equipment substitution will not change our PPG obligations. Additionally, at ADT Solar's option (but at no additional cost to you), ADT Solar may elect to make cosmetic repairs that are not covered by the Limited Warranty or to upgrade or add to any part of the System to ensure that it performs according to the PPG. If your claim is not covered by a Limited Warranty, you may request that ADT Solar make the repair or replacement at your cost and expense. ADT Solar will send a representative to your Property to provide you with a price quote for the requested services. You may then elect whether to have ADT Solar provide the requested services at the quoted price. The System may only be moved by ADT Solar, and only in order to permit you to renovate or repair the Property at your request and your expense. ADT Solar will send a representative to your Property to provide you with a price quote for moving the System. You may then elect whether to have ADT Solar move the System at the quoted price. ANY ACTUAL OR ATTEMPTED INSTALLATION, REPAIR, ALTERATION, REPLACEMENT, MOVEMENT, CHANGE, OR MODIFICATION TO THE SYSTEM MADE BY ANYONE OTHER THAN ADT SOLAR OR ITS APPROVED SERVICE PROVIDERS, OR WITHOUT ADT SOLAR'S PRIOR WRITTEN CONSENT WILL AUTOMATICALLY VOID BOTH THE LIMITED WARRANTY AND THE PPG. LIMITED WARRANTIES AND ADDITIONAL TERMS & CONDITIONS ACKNOWLEDGEMENT DocuSigned by: Customer Signature: �NIA 8731E8CBCD74499,.. ADT Solar Contract V12.22.21 - ADT Solar, LLC (f/k/a Marc Jones Construction, LLC and Sunpro) - License # CVC570681373057, 4492-4494-4496 Eagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 DocuSign Envelope ID: CprB23oo-po79-47ac-e24e-Ap*4e29c41+B Solar Agreement Date: 81712022 You may cancel this transaction, without any penalty or ob|igadon, within three (3) business days from the above date or, if you are 65 years of age or older, you may cancel this Agreement within fifteen (15) business days after the above date. If you cancel, any property traded in, any payments made by you under the contract or sa|e, and any negotiable instrument executed by you will be returned within ten (10) days following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be canceled. If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sa|e, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the seller's expense and risk. If you do make the goods available to the seller, and the seller does not pick them up within twenty (20) days of the date of your notice of cancellation, you may retain or dispose of the goods without any further obligation, If you fail to make the goods available to the seller, or if you agree to return the goods to the seller and fail to do so' then you remain liable for performance ofall obligations under the contract. To cancel this transaction, mail or deliver a signed and dated copy of this cancellation notice, or any other written notice, or send a telegram to the following address no later than midnight of the third business day (or fifteenth business day ifyou are 65years ofage orolder) following the Agreement Date: AOTSolar, LLC 128 NorUlpark Blvd Covington, LA70433 I hereby cancel this transaction, (Date) (Customer's Signature) AoTso|a, conuoov12.zzz1 AoTso|ar' uc(f/k/a wa/c]onesconstmoion. ucand svnpro) License wcvcs7oax/37ao5/' *e2'449* *eo Eagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located ar 128 Northpark Blvd, Covington, LA 70433 DocuSign Envelope ID: cFpo23co-po79-47ac-B24s+\p44e2ec41p13 ka I Agreement Date: 8/7/2022 You may cancel this transaction, without any penalty or obligation, within three (3) business days from b date or, if you are 65 years of age or older, you may cancel this Agreement within fifteen (15) business days after the above date. If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within ten (10) days following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be canceled. If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the seller's expense and risk. f you do make the goodsavailable the ||er, and the seller does not pickthern up within twenty (30)days of the date ofyour notice of cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available tothe seller, orifyou agree to return the goods to the seller and fail to do so' then you remain liable for performance ofall obligations under the contract. cancelTo this transaction, mail or deliver a signed and dated copy of this cancellation notice, or any other written notice,d a telegram to the following address no later than midnight of the third business day (or fifteenth business day if you areG5years ofage orolder) following the Agreement Date: ADT5o|or, LLC 128 Northpark Blvd Covington, LA7O433 | hereby cancel this transaction. (Date) (Customer's Signature) Aorso/arcontract v12.zzz/ AoTso|a,'uc(f&mMor4unescnnstmmuo' L/candsunpro) ncense# 4492'4494*96sag|epaUr place, rampa' aaaal9,oa+5seas35;corporate Offices |no,ted at1zomouhpa,k Blvd, covmgton. Lx/o4as DocuSign Envelope ID: CFFB23CD-FD79-47BC-B24E-AF44E29C41 FB r t r luffiffKaTudw- ACCORDING WHO WORK ON YOUR PROPERTY OR PROVIDE MATERIALS AND SERVICES AND ARE NOT PAID IN FULL HAVE A RIGHT TO ENFORCE THEIR CLAIM FOR PAYMENT AGAINST YOUR PROPERTY. THIS CLAIM IS KNOWN AS A CONSTRUCTION LIEN. IF YOUR CONTRACTOR OR A SUBCONTRACTOR FAILS TO PAY SUBCONTRACTORS, SUB - SUBCONTRACTORS, OR MATERIAL SUPPLIERS, THOSE PEOPLE WHO ARE OWED MONEY MAY LOOK TO YOUR PROPERTY FOR PAYMENT, EVEN IF YOU HAVE ALREADY PAID YOUR CONTRACTOR IN FULL. IF YOU FAIL TO PAY YOUR CONTRACTOR, YOUR CONTRACTOR MAY ALSO HAVE A LIEN ON YOUR PROPERTY. THIS MEANS IF A LIEN IS FILED YOUR PROPERTY COULD BE SOLD AGAINST YOUR WILL TO PAY FOR LABOR, MATERIALS, OR OTHER SERVICES THAT YOUR CONTRACTOR OR A SUBCONTRACTOR MAY HAVE FAILED TO PAY. TO PROTECT YOURSELF, YOU SHOULD STIPULATE IN THIS CONTRACT THAT BEFORE ANY PAYMENT IS MADE, YOUR CONTRACTOR IS REQUIRED TO PROVIDE YOU WITH A WRITTEN RELEASE OF LIEN FROM ANY PERSON OR COMPANY THAT HAS PROVIDED TO YOU A "NOTICE TO OWNER." FLORIDA'S CONSTRUCTION LIEN LAW IS COMPLEX, AND IT IS RECOMMENDED, • AN ATTORNEY. I have read and acknowledge receipt of the notification above: Owner Name: Date: 8/7/2022 Andres Parra The Florida Public Service Commission has adopted rules regarding insurance requirements for solar systems. Your utility company has interpreted those rules to mean that owners of a solar system which is 1 1 .76kW DC / 10.0 kW AC or larger, including those owned by residential customers for their own use, must have general liability insurance for personal and property damage of $1 million or must demonstrate to the utility that they have sufficient financial means to self -insure in that amount. If you do not, the utility can prevent you from interconnecting to the grid; interconnection is required for your solar system to operate. 1►[e•••lldC•1mmaymn3u1`u[�7►�■ T�7i •]TT ITITI7 FLORIDA HOMEOWNERS' CONSTRUCTION RECOVERY FUND PAYMENT, UP TO A LIMITED AMOUNT, MAY BE AVAILABLE FROM THE FLORIDA HOMEOWNERS' CONSTRUCTION RECOVERY FUND IF YOU LOSE MONEY ON A PROJECT PERFORMED UNDER CONTRACT, WHERE THE LOSS RESULTS FROM SPECIFIED VIOLATIONS OF FLORIDA LAW BY A LICENSED CONTRACTOR. FOR INFORMATION ABOUT THE RECOVERY FUND AND FILING A CLAIM, CONTACT THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD AT THE FOLLOWING TELEPHONE NUMBER AND ADDRESS: 2601 BLAIR STONE ROAD, TALLAHASSEE, FLORIDA 32399-0791; 850-487-1395 ADT Solar Contract V12.22.21 - ADT Solar, LLC (f/k/a Marc Jones Construction, LLC and Sunpro) - License # CVC57068/373057, 4492-4494-4496 Eagle Falls Place, Tampa, FL 33619, 866-599-3635; Corporate Offices located at 128 Northpark Blvd, Covington, LA 70433 000uomnE |o:crpezaco'po/y-4roc-B24e-Ar44Ecsc41FB This disclos Itisnot asu PROVIDER: xddr*ao` AoTsolar, L 1eamonxpa cuving¢vn.L cusmmerIE System Inst, Customer smai|:andyi Contract Da is designed to help you understand the key terms of your purchase of a solar electric system ("System"). uzcfor your purchase contract ("Contract).loan nrany other documents associated with this transaction. Information presented below |psubject uo the terms ofyour Contract. Read all documents carefully uoyou fully understand the transaction For more information onbecoming asmart solar consumer please visit Tobetter understand the cost cdthe electricity produced byyour System, please refer cothe separate fonn. SsmCR,lSolar Purchase Disclosure Addendum Estimated Cost Per kWh, INSTALLER: Address: ,C AoTSolar, LLc kBhd / 12amortbparkBlvd k70433 Covington, LA 70433 # (if applicable): I State/County Contractor Andres Pmra ladonAddress: aseSGMorse Willow Ctzephyrhi|b.FLz3s4z i|ingAddress: as8g5Morse Willow nt'zephyrhiUs.FL%354z qo@gma|.cum ': 8/7/2022 PROVIDER: (if Different from installer/Provider): Address: TnL License #: | License # (if applicable) I Email: *NOTE: YOU ARE ENTERING INTO AN AGREEMENT TO PURCHASE A SOLAR ELECTRICITY GENERATING SYSTEM. YOU WILL OWN (NOT LEASE) THE SYSTEM INSTALLED ON YOUR PROPERTY. Your purchase price: List Wany credits, incentives orrebates included inthe above purchase price: *NOTE: Not everyone is eligible for such incentives fully use them. Consult your tax professional or legal professional for further information, Amount you owe Provider atContract signing: Amount you owe Provider at the commencement nY Amount you owe Provider atthe completion of installation: You will make nfinal payment toProvider atthe following time (e.g.intemonnochon): PER LOAN TERMS and for the following amount: U�2,28l Your System: N WILL befinanced U vmm-moTbefinanood;u, u Financing n(System UNKNOWN m Provider NOTE: Ifyour System |sfinanced, carefully read any agreements and/or disclosure forms provided byyour lender. This statement does not contain the terms ofyour financing agreement. K you have any questions about your financing arrangement, contact your finance provider before signing a ssm®RSolar Purchase jocuoign cnveiope iv: Ut-r-bZ,sUU-ruiy-4/bU-bZ4t-Hr44Czy�,:4lt-b Approximate Start Date: 30 days from the date the Agreement is signed I ❑ YOU are or N PROVIDER is responsible for submitting a System or (date). I interconnection application. Approximate Completion Date: 120 days from the date of the Agreement is signed or (date). • The estimated size of your System is: 10.67 kW DC • Estimated gross annual electricity production in kilowatt-hours (kWh) from your System in Year 1: 15,847 ® Estimated annual electricity production decrease due to natural aging of the System: 0.33% • System location on your property: Roof Connectivity: The System ■ WILL ❑ WILL NOT be connected to the electric grid. • At the time of installation, your local utility 0 WILL ❑ WILL NOT credit you for excess energy your System generates. The rules applying to such credit are set by your jurisdiction. "System maintenance" refers to the upkeep and services required or recommended to keep your System in proper operation. System maintenance ❑ IS N IS NOT included for years from (e.g. Provider, Installer, Other). You are required to perform the following System maintenance: SEE OWNER'S MANUAL "System repairs" refers to actions needed to fix your System If it is malfunctioning. System repairs 0 ARE ❑ ARE NOT provided by the MATERIALS MANUFACTURER (e.g. Provider, Installer, Other). If System repairs ARE included, the coverage periods for each hardware corponent of your System (in years) are: SEE MANUFACTURER WARRANTY If System repairs ARE included, the coverage periods for the labortworkmanship for each component of your System (in years) are: 25 YEAR LIMITED WORKMANSHIP WARRANTY PROVIDED BY PROVIDER. SEE CONTRACT TERMS AND CONDITIONS FOR DETAILS Please review your Contract for additional information about any warranties on the System installation and equipment. Note that equipment warranties for hardware are not required to include labor/workmanship. Your Contract may be assigned, sold or transferred by Provider without your consent to a third party that will be bound to all the terms of the Contract. If such a transfer occurs, you will be notified if this will change the address or phone number to use for system maintenance or repair requests. Your roof ■ IS ❑ IS NOT warranted against leaks from the System installation for 10 years by PROVIDER (e.g. Provider, Installer, Other). Provider is providing you with a: ❑ Performance guarantee for __ years Production guarantee for 25 years ❑ No guarantee of performance or production Underperformance or underproduction will be remedied as follows: SEE POWER PRODUCTION GUARANTEE IN CONTRACT You are responsible for property taxes on property you own. Consult a tax professional to understand any tax liability that may result from entering the Contract. SEIACR Solar Purchase Disclosure. © Solar Energy Industries Association v. 2017 Silverado Ranch North C/0 Access Management 5322 Primrose Lake Circle, Suite C Tampa, Ff., 33647 August 29, 2022 Andres F. and Cynthia L. Parra 35996 Morse Willow Court Zephyrhills, FL 33541 RE: Architectural Modification Request Approval for 35996 Morse Willow Court Dear Andres F. and Cynthia L Marra; Please accept this letter as evidence that your Architectural Modification Application has been reviewed by the Architectural Review Committee for Silverado Ranch North, Specifically, you are approved to proceed with the following as submitted: Solar Panels — APPROVED Please note that all work must be perfort-ned in accordance with your community's Governing Documents, any and all permits must be secured by the homeowner, and all applicable building codes and ordinances must be adhered to in relation to this project. It is the lot owner's responsibility to ensure that all municipal processes are completed and approved prior to work commencing. You have up to 90 days from the date of official approval as indicated on this notification, to have the approved work completed. Should you need an extension or will not have the project completed within this time frame, please contact us at (813) 421-9898 or by e-mail at silverado"&,accessdifference,com, Thank you for your compliance and adherence to the Architectural guidelines for the community. Colette Fuller, LCAM Community Association Manager On Behalf of the Board of Directors aoe ID: CFFB23CD-FD79-47BC-B24E-AF44E29C41FB Provider ®I HAS ❑ HAS NOT given you a financial savings estimate based on your purchase. If provided, the savings estimate was calculated based on: Your estimated prior electricity use ❑ Your actual prior electricity use ❑ Your estimated future electricity use Such savings estimate assumes: Your System will last 25 years IN A current estimated utility electricity rate of 0.140108 [cost per kilowatt-hour] during the first year with estimated utility rate increases of 3.5% percent annually. Provider based these estimates on the following source(s): Homeowner's Description Of Utility Bills, US Department of Energy, Equipment Manufacturer(s) If your local utility is providing you credit for excess electricity your System generates, that the utility will continue to credit you based on ESTIMATED FUTURE ❑ CURRENT utility electricity rates ❑ The following costs, expenses, rebates, incentives: NOTE: It is important to understand that future utility electricity rates estimates only. Your future utility rates and utility rate increases may vary. Provider ❑ IS N IS NOT guaranteeing these savings. If Provider is guaranteeing savings, underperformance will be compensated as follows: In addition to any rights you have under state or local law, you 0 HAVE ❑ DO NOT HAVE the rightto terminate your Contract without penalty within three (:3) business days of by notifying Provider in writing at the above address. Provider 0 [DOES ❑ DOES NOT abide by and agree to be bound by the SETA Solar Business Code and its complaint resolution process. For more information about the SETA Solar Business Code and complaint resolution process, please visit www.seia.orglconsumers or email SETA at Actual utility rates may go up or down and actual savings may vary. For further information regarding rates, you may contact your local utility or the public regulation commission that regulates your utility provider. Tax and other state and federal incentives are subject to change. Requirements to interconnect to the grid, which is required for your system to operate properly and for you to obtain any utility bill credits or incentives, are established by the rules of the public regulation commission or other governmental authority regulating your utility, and may be obtained from either the commission or your utility provider. Battery systems, if purchased with your solar system, can provide backup power only to a selected set of essential circuits, and may not power your entire Property. Loads powered by the Battery, and the length of time the loads can be powered, are dependent upon the charge of the Battery at the time of a grid outage, the maximum discharge rate of the inverter, and the Battery discharge programmed settings as determined by the Customer. Customer will need to self -manage their consumption patterns and load for both back-up and self- consumption applications. If you have purchased roofing services from Buildpro, the terms and conditions of that purchase are governed by a separate agreement. SETA® Solar Purchase Disclosure. © Solar Energy Industries Association v. 2017 August 2022 Property Owner: Andres Parra Property Address: 35996 Morse Willow Court, Zephyrhills, FL 33541 RE: Photovoltaic System Roof Installations I have reviewed the existing structure referenced above to determine the adequacy of the existing structure support the proposed installation of an array of solar panels on the roof. Based on my review, the existing structure is adequate to support the proposed solar panel installation. This assessment is based on recent on -site inspection by solar inspectors and photographs of the existing structure. The photovoltaic system is designed to withstand uplift and downward forces; our assessment is regarding the structure's support of the array. Stresses induced by the introduction of individual mount loads on the rafters or truss top chord are within acceptable limits as shown on the attached calculations. The structural considerations used in our review and assessment include the following: Evaluation Criteria: Applied Codes: ASCE 7-16 FBC 2020 NEC 2017 Risk Category: II Design Wind Speed (3-second gust): 137 MPH Wind Exposure Category: C Ground Snow Load:0 PSF Seismic Design Category: D Existing Structure: Roof Material: Shingle Roofing Structure: 2x Wood Rafters/Truss Top Chord Roof Slope: 5/12 .1 .. 1 MANDEVILLE, LA 70471 985.624.5001 INFO@PI-AEC.COM FLORIDA FIRM NO. 30649 PRINCIPAL Infrastructure' e' Architecture ♦ Engineering ♦ Construction www.pi-aec.com ♦ info@pi-aec,com PRINCIPAL Engineering Architecture * Engineering + Construction Page 2 of 3 Effect of the Solar Array on Structure Loading: Gravity Loads: Per IBC Section 1607.12.5.1, the areas of the roof where solar panels are located are considered inaccessible, and therefore not subject to roof Live loading. Live load in these areas is replaced by the dead load of the solar array, 3 psf. The total gravity load on the structure is therefore reduced and the structure may remain unaltered. Connections of the mounts to the underlying structure are to be installed in a staggered pattern, except at the array ends, to distribute the loading evenly to the roof structure. The stresses within the rafters or truss top chord due to the introduction of discrete mount loads are within acceptable 1 imits, as shown on the attached calculations. Wind Load: The solar panel array will be flush mounted (no more than 6" above the surrounding roof surface, and parallel to the roof surface. Any additional wind loading on the structure due to the presence of the array is negligible. The array structure is designed by the manufacturer to withstand uplift and downward forces resulting from wind and snow loads. The attached calculations verify the capacity of the connection of the solar array to the roof to resist uplift due to wind loads, the governing load case. Snow Load: The reduced friction of the glass surface of the solar panels allows for the lower slope factor (Cs) per Section 7.4 of ASCE 7-16 resulting in a reduced design snow load for the structure. This analysis conservatively considered the snow load to be unchanged. Seismic Load: Analysis shows that additional seismic loads due to the array installation will be small. Even conservatively neglecting the wall materials, the solar panel installation represents an increase in the total weight of the roof and corresponding seismic load of less than 10%. This magnitude of additional forces meets the requirements of the exception in Section 11BA of ASCE 7-16 . The existing lateral force resisting system of the structure is therefore allowed to remain unaltered. CE STOF 0 ®tea. PRINCIPAL ENGINEERING, INC. 1011 N. CAUSEWAY BLVD. STE 19 MANDEVILLE, LA 70471 985.624,5001 INFO@PI-AEC.COM FLORIDA FIRM NO. 30649 "Improving the PRINCIPAL Infrastructure of our World" PRINCIPAL Engineering Architecture + Engineering + Construction Page 3 of 3 Conclusion: To the best of my professional knowledge and belief, the subject construction and photovoltaic system installation will be in compliance with all state and local building codes and guidelines in effect at the time of our review. Limitations: Engineer's assessment of the existing structure is based on recent field reports and current photographs of the elements of the structure that were readily accessible at the time of inspection. The design of the solar panel racking (mounts, rails, connectors, etc.), connections between the racking and panels, and electrical engineering related to the installation are the responsibility of others. The photovoltaic system installation must be by competent personnel in accordance with manufacturer recommendations and specifications and should meet or exceed industry standards for quality. The contractor is responsible for ensuring that the solar array is installed according to the approved plans and must notify the engineer of any undocumented damage or deterioration of the structure, or of discrepancies between the conditions depicted in the approved plans and those discovered on site so that the project may be reevaluated and altered as required. Engineer does not assume any responsibility for improper installation of the proposed photovoltaic system. 0 a 113 1 ill to 191-110 a MANDEVILLE, LA 70471 985.624.5001 INFO@PI-AEC.COM FLORIDA FIRM NO. 30649 "Improving the PRINCIPAL Infrastructure qf our World' Uplift and Wind Downforce Calculation Summary (ASCE 7-16) Mount, Rack, & Panel Proportioning Point Load Check and Rafter Stress Analysis Property Owner: Andres Parra Max. Individual Panel Dimensions Project Address: 35996 Morse Willow Court Length (in) Width (in) Area (sf) City, State: Zephyrhills, FL 33541 77 39 20.85 Building Characteristics, Design Input, and Adjustment Factors Roof Dimensions: Length: 73 greater Dimension 73 Width: 50 Least Dimension: SO Roof Height (h): 15 Fig 304-1, valid under 60' ✓ Pitch: on 12 = 22.6' Must be less than 45' ✓ Roof Configuration Hip Roof Structure - 2x Truss Top Chord Roof Material Plywood Risk Category:; 11 Basic Wind Speed: 137 From26.5-1 Exposure Category: C Fig.263 Topographic Factor (KZJ 1.21 Fig. 26.8-1 Wind pressure @ h=30, pnetso See Table Below Flg� 30.4-1 Ht. & Exposure Adjustment (h) 1.21 Fig. 30,4-1 Adjusted Wind Pressures, ,p et See Table Below Eq. 30.4-1 Effective Wind Area (sf): 10.43' (Area per individual mount) Roof Zone Strip (a), in ft Fig; 30.4-1, Note '5 1- Least Roof Horizontal Dimension (L or W) x 0.10 5 2 - Roof Height x 0.4 6 3 - Least Roof Horizontal Dimension (L or W) x 0.04 2 4 - Least of (1) and (2) 5 5 5 - greater of (3) and (4) 5 6 - greater of (5) and 3 feet a=I Net Design Pressures, pnet (Fig 30.4.1),iComponents & Cladding Uplift (-psf) Factored Pressure P30net (KztP90net (0.6W, ASCF 7-16)0 Zone 1 46.5 68.1 40.9 20° 8 <_ 27° Zone'2e, r,3 4. 94.0 5 ,4 e • IN 9—Al Eq 01191 ILI I• , MANDEVILLE, LA 70471 985.624.5001 INFO@PI-AEC.COM Snow Load Ground now Load, ­p, Terrain Category: Exposure Exposure FactorCe Thermal Factor, Ct Importance Factor, 1, Roof Configuration Roof Slope Distance from Eave to Ridge pm, Minimum required Snow Load pf, Calculated Snow Load ,pf, Design Snow Load 0.0 From ASCE 7 or AHJ Para 6.5.6.3 Table 7-2 Table 7-3 Table 1.5.2 Para. 7.3.4 Eq. 7.3-1 I I C Fully 0.9 12 U Hip 22:6* 25.0 N/A 0.00 0.00 psf Zone 1: 2 rails, mounts @ 2 ft. o.c. Zone 2r: 3 rails, mounts @ 4 ft. o.c. Zone I': N/A Zone 3: 3 rails, mounts @ 4 ft. o.c. Zone 2: N/A Zone 3e: N/A Zone 2e: 3 rails, mounts @ 4 ft. o.c. Zone 3r: N/A Zone 2n: N/A PRINCIPAL ENGINEERING, INC. 1011 N. CAUSEWAY BLVD. STE 19 MANDEVILLE, LA 70471 985.624.5001 INFO@PI-AEC.COM FLORIDA FIRM NO. 30649 PHOTOVOLTAIC ROOF MOUNT SYSTEM •, MORSE WILLOW CT, ZEPHYRHILLS, FL 33541 PROJECT DATA • PROJECT 35996 MORSE WILLOW CT, ADDRESS ZEPHYRHILLS, FL 33541 OWNER: ANDRES PARRA CONTRACTOR: ADT SOLAR LLC PHONE: (985) 238-0864 DESIGNER: ESR SCOPE: 10.665 KW DC ROOF MOUNT SOLAR PV SYSTEM WITH 27 CANADIAN SOLAR CS3N-395MS 395W PV MODULES WITH 27 ENPHASE IQ8PLUS-72-2-US MICROINVERTERS DERATE MAIN BREAKER FROM 200A RATED TO 175A AUTHORITIES HAVING JURISDICTION: BUILDING: ZEPHYRHILLS, CITY OF (FL) ZONING: ZEPHYRHILLS, CITY OF (FL) UTILITY: DUKE ENERGY (FL) SHEETINDEX PV-1 COVER SHEET PV-2 SITE PLAN PV-3 ROOF PLAN & MODULES PV-4 ELECTRICAL PLAN PV-5 STRUCTURAL DETAIL PV-6 ELECTRICAL LINE DIAGRAM PV-7 WRING CALCULATIONS PV-8 LABELS PV-9 PLACARD PV-10 JHA FORM PV-11 MICRO INVERTER CHART PV-12+ EQUIPMENT SPECIFICATIONS 1. ALL COMPONENTS ARE UL LISTED AND CEC CERTIFIED, WHERE WARRANTED. 2, THE SOLAR PV SYSTEM WILL BE INSTALLED IN ACCORDANCE WITH ARTICLE 690 OF THE NEC 2017. 3. THE UTILITY INTERCONNECTION APPLICATION MUST BE APPROVED AND PV SYSTEM INSPECTED PRIOR TO PARALLEL OPERATION. 4. ALL CONDUCTORS OF A CIRCUIT, INCLUDING THE EGC, MUST BE INSTALLED IN THE SAME RACEWAY, OR CABLE, OR OTHERWISE RUN WITH THE PV ARRAY CIRCUIT CONDUCTORS WHEN THEY LEAVE THE VICINITY OF THE PV ARRAY. 5. WHERE METALLIC CONDUIT CONTAINING DC CONDUCTORS IS USED INSIDE THE BUILDING, IT SHALL BE IDENTIFIED AS "CAUTION: SOLAR CIRCUIT" EVERY 1 OFT. 6. HEIGHT OF THE AC DISCONNECT SHALL NOT EXCEED 6-7" PER NEC CODE 240.24. 7. A GROUNDING ELECTRODE SYSTEM IN ACCORDANCE WITH CEC 690.47 AND 250.50 THROUGH 60 AND 250-166 SHALL BE PROVIDED. PER NEC GROUNDING ELECTRODE SYSTEM OF EXISTING BUILDING MAY BE USED AND BONDED TO THE SERVICE ENTRANCE. IF EXISTING SYSTEM IS INACCESSIBLE OR INADEQUATE A SUPPLEMENTAL GROUNDING ELECTRODE WILL BE USED AT THE INVERTER LOCATION CONSISTING OF A UL LISTED 8 FT. GROUND ROD WITH ACORN CLAMP. GROUNDING ELECTRODE CONDUCTORS SHALL BE NO LESS THAN #8 AWG AND NO LARGER THAN #6 AWG COPPER AND BONDED TO THE EXISTING GROUNDING ELECTRODE TO PROVIDE FOR A COMPLETE SYSTEM. 8, PHOTOVOLTAIC MODULES ARE TO BE CONSIDERED NON-COMBUSTIBLE. 9. PHOTOVOLTAIC INSTALLATION WILL NOT OBSTRUCT ANY PLUMBING. MECHANICAL, OR BUILDING ROOF VENTS, 10. ALL WIRING MUST BE PROPERLY SUPPORTED BY DEVICES OR MECHANICAL MEANS DESIGNED AND LISTED FOR SUCH USE. WIRING MUST BE PERMANENTLY AND COMPLETELY HELD OFF THE ROOF SURFACE. 11. ALL SINAGE TO BE PLACED IN ACCORDANCE WITH THE LOCAL BUILDING CODE. IF EXPOSED TO SUNLIGHT, IT SHALL BE UV RESISTANT. ALL PLAQUES AND SINAGE WILL BE INSTALLED AS REQUIRED BY THE NEC AND AHJ. 12. INVERTER(S) USED IN UNGROUNDED SYSTEM SHALL BE UL 1741 LISTED. 13. THE INSTALLATION OF EQUIPMENT AND ALL ASSOCIATED WIRING AND INTERCONNECTION SHALL BE PERFORMED ONLY BY QUALIFIED PERSONS [NEC 690.4(C)] 14. ALL OUTDOOR EQUIPMENT SHALL BE NEMA 3R RATED (OR BETTER), INCLUDING ALL ROOF MOUNTED TRANSITION BOXES AND SWITCHES. 15. ALL EQUIPMENT SHALL BE PROPERLY GROUNDED AND BONDED IN ACCORDANCE WITH NEC ARTICLE 250. 16. SYSTEM GROUNDING SHALL BE IN ACCORDANCE WITH NEC 690.41. 17. PV SYSTEM CIRCUITS INSTALLED ON OR IN BUILDINGS SHALL INCLUDE A RAPID SHUTDOWN FUNCTION IN ACCORDANCE WITH NEC 690.12 18. DISCONNECTING MEANS SHALL BE LOCATED IN A VISIBLE, READILY ACCESSIBLE LOCATION WITHIN THE PV SYSTEM EQUIPMENT OR A MAXIMUM OF 10 FEET AWAY FROM THE SYSTEM [NEC 690.13(A)] 19. ALL WIRING METHODS SHALL BE IN ACCORDANCE WITH NEC 690.31 20. WORK CLEARANCES AROUND ELECTRICAL EQUIPMENT WILL BE MAINTAINED PER NEC 110.26(A)(1), 110.26(A)(2) AND 110.26(A)(3). 21. ROOFTOP MOUNTED PHOTOVOLTAIC PANELS AND MODULES SHALL BE TESTED, LISTED & IDENTIFIED IN ACCORDANCE WITH UL1703 22. ELECTRICAL CONTRACTOR TO PROVIDE CONDUIT EXPANSION JOINTS AND ANCHOR CONDUIT RUNS AS REQUIRED PER NEC. •-,i. i . ii i • • • f- OTAN mm- IMMUNE i ii i i • • • • i' i.!2017 • • • mow.Solar �I�� �IGOI III 22171 MCH -D PHONE:0 REVISIONS DESCRIPTION DATEINITIAL DESIGN 08/26/2022 e •r I� it PRINCIP ENGINE ING INC. 011 N. CAUSEWAY Irl MANDEVILLE, LA 70471 985.624.5001 INFO@PI-AEC.COM FLORIDA FIRM :30649 PROJECTI, & ADDRESS .` co wt t • • t cr C.0 • t SHEET � NAM COVER SHEET HEET SIZE ANSI it i SHEET1 NOTE: VISIBLE, LOCKABLE, LABELED AC DISCONNECT LOCATED WITHIN 1oo+UTILITY METER � " �04n�-���� | r------. � /\ | ~�*I 7-,sTORY | 1 SITE PLAN . � / / ---------------------------------------------- PROPERTY __ L|NE �*��» ^�** \ ��� � �°� L_ ROOF #1 �?)CANAU�NSOLAR C83N�85MS 3S5VVMONO MODULES YWTHENPHASE (N)ENPHA8ECQK8B|NERBOX |O8PLUS'2'2'USM|CRO|NVERTERS (N) VISIBLE, LOCKABLE, LABELED NON -FUSED ACDISCONNECT (LOCATED VNTH|N1�OFUTILITY METER) (E)UTILITY METER/MAIN COMBO (OUTS|DE) IN DESIGN SPECIFICATION OCCUPANCY: 11 CONSTRUCTION: SINGLE-FAMILY ZONING: RESIDENTIAL A Solar PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV 3 PRINCIPAL STATIE Of o PRINCIPAL ENGINEERING, INC. FLORIDA FIRM NO. 30649 PROJECT NAME & ADDRESS LLI Lij co N SHEET NAME SITE PLAN SHEET SIZE ANSI B SHEET NUMBER ROOF DESCRIPTION ROOF TYPE ASPHALT SHINGLE ROOF ROOF I PITCH AZIMUTH TRUSS SIZE TRUSS SPACING CANAOIANSOLAR CS3N'395MS395YV MODULES IJn -JUNCTK]NBOX [�� 'S0LADECK -INVERTER FC 8] - COMBINER BOX [T�l �� -ACDISCONNECT FUMI -UT|L|TYMETER hwsp �� 'KAA|NSERVICE PANEL - VENT, ATTIC FAN (ROOF OBSTRUCTION) � -ROOFATTACMMENT I -- -- TRUSS ---� -CONDUIT IA PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 PRINCIPAL fir STATE OF PRINCIPAL ENGINEERING, INC. 985,624.5001 FLORIDA FIRM NO. 30649 PROJECT NAME & ADDRESS uj 0— LLI co N SHEET NAME ROOF PLAN & MODULES SHEET SIZE ANSI B SHEET NUMBER ~�— �� O � _"oSS0� I aTA L& W o0a� SEE (28zV-5)FOR ENLARGED VIEW alFAUT1101�� (E) ASPHALT SHINGLE ROOF \-- (E)ASPHALT SHINGLE ROOF Note 1:VVindsoegdvalue iSdesign 3-sBCguStina000rdmnoewdhAGCE7'1O Note 2:a\Luobolt shall bemounted into rafters b)NotifvEngineer immediately ifconditions differ or prevent installation per plan. Note 3:These drawings were prepared under mys iaon. ' | have researched the code and iothe best ofmyknowledge - And belief, these drawings comply with the 3O2OFlorida � Building Code. _ Note 4:Installer shall adjust mount spacing bvzone k}match . prescribed values onengineer's calculation letter , Note5: Maximum rail cantilever distance beyond outermost mount im One-third the zone -specific mount spacing, 'END/MID CLAMP =-RRATEDT-Q0LT FLANGE NUT N)UN|RACFLASHLOC 'OMPNT Solar PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/2612022 PRINCIPAL STATIE OF AV to PRINCIPAL ENGINEERING, INC. FLORIDA FIRM NO. 30649 PROJECT NAME & ADDRESS SHEET NAME STRUCTURAL DETAIL SHEET SIZE ANSI B SHEET NUMBER DC SYSTEM SIZE: 27 x 395 = 10.665KW DC AC SYSTEM SIZE: 27 X 290 = 7.830KW AC (27) CANADIAN SOLAR CS3N-395MS 395W MONO MODULES WITH (27) ENPHASE IQ8PLUS-72-2-US MICROINVERTERS LOCATED UNDER EACH PANEL (240V) (3) BRANCH CIRCUITS OF 9 MODULES CONNECTED IN PARALLEL BACKFEED BREAKER CALCULATION (120% RULE): (MAIN BUSS X 1.2 - MAIN BREAKER) - (INVERTER CURRENT-1.25) (200A X 1.2 - 175A) - (408375A) (40.8375A) HENCE OK glEt. ME ILMLS 2 CANADIAN SOLAR CS3N-395MS 395W MODULES BRANCH#1 1 2 3 0 0 0 0 0 0 A BRANCH#2 L2 3 0 0 0 l 3 A A, A + -1 1+ 1� 0 11 �l 0 0 BRANCH#3 1 2 3 0 0 0 + L BRANCH TERMINATOR (ET -TERM) ENPHASE IQ8PLUS-72-2-US MICROINVERTERS LOCATED UNDER EACH PANEL (240V) ELECTRICAL LIINIE DIAGRAM S. SCALE: N.T. INTERCONNECTION NOTES: 1. INTERCONNECTION SIZING, LIMITATIONS AND COMPLIANCE GROUNDING & GENERAL NOTES: DETERMINED IN ACCORDANCE WITH (NEC 705.121, AND [NEC 690.591. t PV GROUNDING ELECTRODE SYSTEM NEEDS TO BE INSTALLED IN 2. GROUND FAULT PROTECTION IN ACCORDANCE WITH [NEC 215.91, ACCORDANCE WITH [NEC 690,431 [NEC 230.951. 2, PV INVERTER IS UNGROUNDED, TRANSFORMER -LESS TYPE. 3. ALL EQUIPMENT TO BE RATED FOR BACKFEEDING. 3. DC GEC AND AC EGC TO REMAIN UNSPLICED, OR SPLICED TO EXISTING 4. PV BREAKER TO BE POSITIONED AT THE OPPOSITE END OF THE ELECTRODE BUSBAR RELATIVE TO THE MAIN BREAKER. 4, ANY EXISTING WRING INVOLVED WITH PV SYSTEM CONNECTION THAT IS FOUND TO BE INADEQUATE PER CODE SHALL BE CORRECTED PRIOR TO FINAL DISCONNECT NOTES: INSPECTION. 1. DISCONNECTING SWITCHES SHALL BE WIRED SUCH THAT WHEN 5. SOLADECK QUANTITIES, AND PLACEMENT SUBJECT TO CHANGE IN THE THE SWITCH IS OPENED THE CONDUCTORS REMAINING LIVE ARE FIELD - SOLADECK DEPICTED ON ELECTRICAL DIAGRAM REPRESENT WIRE CONNECTED TO THE TERMINALS MARKED "LINE SIDE" (TYPICALLY TYPE TRANSITIONS. THE UPPER TERMINALS) 6. AC DISCONNECT NOTED IN EQUIPMENT SCHEDULE OPTIONAL IF OTHER 2.AC DISCONNECT MUST BE ACCESSIBLE TO QUALIFIED UTILITY AC DISCONNECTING MEANS IS LOCATED WITHIN 10'OF SERVICE DISCONNECT. PERSONNEL, BE LOCKABLE, AND BE A VISIBLE -BREAK SWITCH 7. RACEWAYS AND CABLES EXPOSED TO SUNLIGHT ON ROOFTOPS SHOULD BE 3. DISCONNECT MEANS AND THEIR LOCATION SHALL BE IN INSTALLED MORE THAN 7/8" ABOVE THE ROOF USING CONDUIT SUPPORTS. ACCORDANCE WITH [NEC 225.311 AND (NEC 225,321. 8. VERIFY LIFER/EXISTING ROD OR ADD TWO GROUNDING RODS(5/8" X 8' EMBEDMENT) SPACED 6 FEET MINIMUM APART. 9. BOND COLD WATER AND GAS LINES(IF PRESENT) TO GROUNDING ELECTRODE CONDUCTOR TO UTILITY GRID Ll L2 N LINE LOAD BACKFEED BREAKER REF 5OA/2P 2017 NEC 705.12(13)(2)(3)(b) ENPHASE IQ COMBINER X-IQ-AM1-240-4/4C 120/240VAC, 1+ , 3W 125A RATED BUS BAR, NEMA 3R SOLAR LOADS ONLY 4 UL 1741 COMPLIANT IQ GATEWAY: PER PV NON -FUSED MANUFACTURER AC DISCONNECT r-L2� 10 SPECIFICATIONS, EITHER 240V, 1 �, 3W N 1 OA OR 15A BREAKER IS GATEWAY 60A RATED G SUITABLE FOR T_ F NEMA 3R USE 1 1 OA/2P F LINE 0-- 20A/2P Ll L2 SOLADECK, 20N2P I --- 0 600V, NEMA 3R, 0-- _01. I 0— UL LISTED L2 LOAD NAG 20AJ2P -------- 0— 1 Ll G L2 N N - - ----- 0— VISIBLE, LOCKABLE, LABELED AC DISCONNECT LOCATED WITHIN 10' OF UTILITY METER (GN)GENERAL NOTES: 3 1 1. CONDUIT TO BE UL LISTED FOR WET LOCATION AND UV PROTECTED (EX. -EMT, SCH 80 PVC OR RMC). 2. FMC MAYBE USED IN INDOOR APPLICATIONS WHERE PERMITTED BY NEC ART. 348 If/ BI-DIRECTIONAL UTILITY METER 120/24OVI 1�, 3-W (N) MAIN BREAKER TO HOUSE 240 V, 175A/2P (E) METER PANEL COMBO,SQUARE D 200A RATED, 240V LOAD/LINE SIDE N INTERCONNECTION ::3 AT MAIN PANEL j G1 PER ART. 705.12 (GEC EXISTING GROUNDING ELECTRODE SYSTEM TO EARTH REF. NEC 250.52,250.53(A) (SEE GROUNDING & GENERAL NOTES #8 & 9) 1611 (N) SUB BREAKER TO HOUSE 240 V, 175A/2P (E) SUB PANEL PANEL,SQUARE D 200A RATED, 240V CONDUIT QTY CONDUCTOR INFORMATION CONDUIT TYPE SIZE Q CABLE (6) #12AWG - (Ll & L2 NO NEUTRAL) N/A N/A (1) #6AWG - BARE COPPER IN FREE AIR (6) #10AWG - THWN-2 (Ll, L2) (EXTERIOR) #10/2 ROMEX EMT, LFMC OR PVC 1" (1) #1 OAWG - THWN-2 GND IN ATTIC (2) #6AWG - THWN-2 (L1,L2) (1) #6AWG - THWN-2 N EMT, LFMC OR PVC (1) #1 OAWG - THWN-2 GND (2) #6AWG -1 THWN-2 (L1,L2) (1) #6AWG - THWN-2 N EMT, LFMC OR PVC —0) #10AWG- THWN-2GND r I 22171 MICH RD MANDEVILLE, LA 70471 PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 PRINCIPAL sod *LJ. H0(j C E IVS 4� No, 64501 F PRINCIPAL ENGINEERING, INC. 1011 N. CAUSEWAY BLVD. STE 19 MANDEVILLE, LA 70471 98S.624.5001 INPO@PI-AEC.COM FLORIDA FIRM NO. 30649 PROJECT NAME & ADDRESS T_ 114, < 0 Lx) cy) w < U IL z CL m U) U) C) ry c) W Fn 0 2 w (.0 z < LO Lu co N SHEET NAME ELECTRICAL LINE DIAGRAM SHEET SIZE ANSI B 11 " X 17" SHEET NUMBER PV-6 INVERTER SPECIFICATIONS MANUFACTURER / MODEL # ENPHASE IQ8PLUS-72-2-US MICROINVERTERS MIN/MAX DC VOLT RATING 30V MIN/ 58V MAX MAX INPUT POWER 235W-440W NOMINAL AC VOLTAGE RATING 240V/ 211-264V MAX AC CURRENT 1.21A MAX MODULES PER CIRCUIT 113 (SINGLE PHASE) MAX OUTPUT POWER 1290 VA SOLAR MODULE SPECIFICATIONS MANUFACTURER / MODEL # CANADIAN SOLAR CS3N-395MS 395W MODULE VMP 37.OV IMP 10.68A VOC 44.3V ISC 11 A4A TEMP. COEFF. VOC -0.26%/°C MODULE DIMENSION 76.4"L x 41.3"W x 1.38"D (in Inch) AMBIENT TEMPERATURE SPECS RECORD LOW TEMP I-1' AMBIENT TEMP (HIGH TEMP 2%) 1 33° MODULE TEMPERATURE COEFFICIENT OF Voc I -0.26e/d°C PERCENT OF VALUES NUMBER OF CURRENT CARRYING CONDUCTORS IN EMT .80 4-6 .70 7-9 .50 10-20 i i son• a ;. t Residential Standard Calculation Version 2011 L STEP 4 Article 220 42 & 220 52 - j q. ft w 3000 General Lighting toad 2 Small Appliance 1 Laundry circuit Gen.Lgt, Sm Apo.& Laun. Load STEP 2 Article 220.50 & 220.51 G1 AM Condenser & Fixed Electric Space Heating d t m + 5,700 VA Mill 1 aw A/C s2 + VA AHU 2 Setecz '1I'. VA AHU 31 SAIII + At, -4 + VA AHU 4 i S.*e A/r v5 VA AHU 5 [Select STEP 3 . Article 220.53 C 4.50D VA +r 1 Water Heater Ia,4m uA 1 Refrigerator Freezer �1010 vA v 's 1 Dishwasher v9n vA .r. 1 Disposal �4cza VA w 1 R t Hood 11,5i0 VA 1 Microwave Microwave 1170 VA.... w. Mini Reffig ,�mOq vA r Wine Gr tnsta Hot 1,500 VA v' Ironing Center 0..: select '•..',. Jacuzzi Tub u select • Sprinkler Pump ew o V : Well Pump rSMea �a1 Fountain Pump �sek x Elevator Pool Equip. Panel [� GATES Other bad 9,000 VA 3,000 VA 1,500 VA 13,5W VA 3,000 VA @ 100%= 10,500 VA @ 35% = VA @ 25%= SQ511997 Andres Penal Marc Junes Construction, LLC Sunpro Solar 0 0 0 811fiQM 1133 3,000 VA 3,675 VA VA General Lighting Demand Load fly Total 1 5,800 VA F1 +' Heating Load 5,800 VA VA Q!Y" CU Load 6,500 VA VA Qtv VA 2L1 ♦ Greater of Heat @ 100%vswc @ 100% VA Q Appliance Demand Load 4,500 VA 1,400 VA Dryer Demand Load VA 1,030 VA Range Demand Load 690 VA 400 VA Service Demand 1,630 VA VA Demand Load VA VA Neutral Demand VA VA Min.Service Req. VA VA Min. Feeder size VA Min. Neutral size VA Eq. Grding Cond, VA VA 100! Demand VA No Demand VA No Demand Total Appliance Load 9,650 VA 4 or more demand @ 75% plus lfxt°fo demand loads STEP 4 Article 220.54 Electric Clothes Dryers 5,000 VA STEP 5 Article 220.55 Electric Ranges 10,000 W Coi C demand 8000 or Number of appliances Cooktop Cot 8 demand [!. 0-k Sox for Gas flange Cooktop Cot 8 demand Ovens) Cod 8 demand Owens) Col 8 demand Number of appliances 0 Din. Faemr 0% Cooktop & Oven Demand Load W 6,675 VA 6,500 VA 7,238 VA 5,000 VA 8,000 VA 33,413 VA 139 A 82 A 150 A 1 4 6 Capper 7,238 VA Continuous Non -continuous Motors _ Motors [ r T mI 240, isz:`�ct t: F_ P4(#4 i2ieft A 240v !select '+i` lJ 240v select T 3 240v ail t +• [,J 24N Sect fi 24N l t ♦� ,_{ 240v selrx • [, 240v iselecz •f [i 240v 0.0 Motor Neutral Load Max.Unbatanced Neutral Load Pool Panel Feeder Calculation {sr_e Noe) ContEl inuous Motors 0 ...... Non -continuous 0 .... , . Spa heater 11 kVA Pool heater 3 5 ton Pool heater 5 ton Pool Light Ise+ 0 - .. $kJwef i seed T 0 Ll 24t5v Omer wad 0 � z40v A S N 0 0 0 fl 0 0 0: 0 g 0 0 0 0 0 0 0 0 0 0 0 ELECTRICAL 1 . ALL EQUIPMENT TO BE LISTED BY UL OR OTHER NRTL, AND LABELED FOR ITS APPLICATION. 2. ALL CONDUCTORS SHALL BE COPPER, RATED FOR 600 V AND 90 DEGREE C WET ENVIRONMENT, 3. WIRING, CONDUIT, AND RACEWAYS MOUNTED ON ROOFTOPS SHALL BE ROUTED DIRECTLY TO, AND LOCATED AS CLOSE AS POSSIBLE • THE NEARESTOR WORKING4. a•aAROUND a AND tEQUIPMENTtCOMPLY110.26. 5. DRAWINGS INDICATE THE GENERAL ARRANGEMENT OF SYSTEMS. CONTRACTOR SHALL FURNISH ALL NECESSARY OUTLETS, SUPPORTS, FITTINGS AND ACCESSORIES TO FULFILL APPLICABLE CODES AND STANDARDS. 6. WHERE SIZES OF SOLADECK RACEWAYS, AND CONDUITS ARE NOT SPECIFIED, THE CONTRACTOR SHALL SIZE THEM ACCORDINGLY. MODULE7ALL WIRE TERMINATIONS SHALL BE APPROPRIATELY LABELED AND READILY VISIBLE. -• • : •s r •D--•- RAIL, MODULEGROUNDING CLIP MANUFACTURER'S INSTRUCTION. 9. _-•- RAIL TOBONDED • • • •.. OR • s D i -i -A•CONDUCTORS,' OR • -ASSOCIATED WITH THE • 1 - PV SYSTEM SHALL RATED • AT LEAST n 22171 MCH RD MANDEVILLE, LA 70471 PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 PRINCIPAL . srxvcrss dim _Qz. ° ° « No. 64501 i '+ N PRINCIPAL ENGINEERING, INC. 1011 N. CAUSEWAY BLVD. STE 19 MANDEVILLE, LA 70471 985,624.5001 INFO@PI-AEC.COM FLORIDA FIRM NO. 30649 PROJECT NAME & ADDRESS 0 ® co Lli �_ J Q LL_ a, Uj ii) Cn ® BUJ Li.! clL W 2 Cl_ 0 to LLI } Z Q W N SHEET NAME WIRING CALCULATIONS SHEET SIZE ANSI B 11" X 17" SHEET NUMBER PV-7 LABEL-1: LABEL LOCATION: AC DISCONNECT ELECTRICAL SHOCK HAZARD TERMINALS ON THE LINE AND LOAD SIDES MAY BE ENERGIZED IN THE OPEN POSITION LABEL- 2: LABEL LOCATION AC DISCONNECT COMBINER MAIN SERVICE PANEL SUBPANEL MAIN SERVICE DISCONNECT CODE REF: NEC 690.13(B) LABEL- 3: LABEL LOCATION: PRODUCTION METER UTILITY METER MAIN SERVICE PANEL SUBPANEL CODE REF: NEC 705.12(C) & NEC 690.59 Boom TURN OFF PHOTOVOLTAIC AC DISCONNECT PRIOR TO WORKING INSIDE PANEL LABEL- 4: LABEL LOCATION: MAIN SERVICE PANEL SUBPANEL MAIN SERVICE DISCONNECT COMBINER CODE REF: NEC 110.27(C) & OSHA 1910A45 (0 (7) LABEL- 5: LABEL LOCATION MAIN SERVICE PANEL (ONLY IF SOLAR IS BACK -FED) SUBPANEL (ONLY IF SOLAR IS BACK -FED) CODE REF: NEC 705,12(D) & NEC 690.59 POWER SOURCE OUTPUT CONNECTION. DO NOT RELOCATE THIS OVERCURRENT DEVICE LABEL- 6: LABEL LOCATION MAIN SERVICE PANEL (ONLY IF SOLAR IS BACK -FED) SUBPANEL (ONLY IF SOLAR IS BACK -FED) CODE REF: NEC 705.12(B)(3)(2) SOLAR PV SYSTEM EQUIPPED WITH RAPID SHUTDOWN TURN RAPID SHUTDOWN SWITCH TO THE "OFF" POSITION TO SHUT DOWN PV SYSTEM AND REDUCE SHOCK HAZARD IN THE ARRAY SOLAR IV PANELS I]- . CODE REF: IFC 605.11.3.1(1) & NEC 690.56(C) LABEL- 10 LABEL LOCATION MAIN SERVICE PANEL SUBPANEL AC DISCONNECT CODE REF: NEC 690.54 LABEL- 11 LABEL LOCATION MAIN SERVICE DISCONNECT (ONLY IF MAIN SERVICE DISCONNECT IS PRESENT) CODE REF: NEC 690.1 3(B) a r ,,:)oi 22171 MCH RD MANDEVILLE, LA 70471 PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 PRINCIPAL i - H 0 u C E 41 0 No. 64501 F ID .... PRINCIPAL ENGINEERING, INC. 1011 N. CAUSEWAY BLVD. STE 19 MANDEVILLE, LA 70471 985.624,5001 INFO@PI-AEC.COM FLORIDA FIRM NO. 30649 PROJECT NAME & ADDRESS < 0 LO cy) cy) U.j c) < LL CL Lij Lli cl) C) ry () LLJ �5 0 Of 2 U-1 0 (D 7- cr_ m z 0) CL < L0 LL] cl) N SHEET NAME LABELS SHEET SIZE ANSI B 11 " X 17" SHEET NUMBER PV-8 NAM"Alk"no-PL MULTIPLE SOURCES OF l T .' SOURCESPOWER TO THIS BUILDING IS ALSO SUPPLIED FROM THE FOLLOWING •NNECTING MEANS LOCATED AS SHOWN: s •. ENPHASE COMBINER BOX AC DISCONNECT UTILITY METER/MAIN COMBO (OUTSIDE) SUB PANEL mWalmiralwA �irf\1•f►�J��1P►YR'•if'Ii'I�l�J��i'1'��'Il�Ea11'lrl+. 4 ! e t ri Miyd l i A; PLAQUESr E WITHIN] NEC .•! . 705.101) 1. LABELS CALLED OUT ACCORDING TO ALL COMMON CONFIGURATIONS. ELECTRICIAN TO DETERMINE EXACT REQUIREMENTS IN THE FIELD PER CURRENT NEC AND LOCAL CODES AND MAKE APPROPRIATE ADJUSTMENTS. 2. LABELING REQUIREMENTS BASED ON THE 2017 NATIONAL ELECTRIC CODE, OSHA STANDARD 19010.145, ANSI Z535. 3. MATERIAL BASED ON THE REQUIREMENTS OF THE AUTHORITY HAVING JURISDICTION. 4. LABELS TO BE OF SUFFICIENT DURABILITY TO WITHSTAND THE ENVIRONMENT INVOLVED [NEC 110.21] 5. LABELS TO BE A MINIMUM LETTER HEIGHT OF 3/8", WHITE ON RED BACKGROUND; REFLECTIVE, AND PERMANENTLY AFFIXED [IFC 605.11.1.11 a� az . , 22171 MCH RD MANDEVILLE, LA 70471 PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 PRINCIPAL iPrilS g� ij c�s �� °R .� H 0j Q�Jq�g���� m• art *'*� . • No. 64541 ° F d�rra:� #ata PRINCIPAL ENGINEERING, INC. 1011 N. CAUSEWAY BLVD. STE 19 MANDEVILLE, LA 70471 985.624.5001 INFO@PI-AEC.COM FLORIDA FIRM NO. 30649 PROJECT NAME & ADDRESS S et O co ui J_ Q u Z U) 0 rv-U� W 121_ W cr- < LO Lu co N SHEET NAME PLACARD SHEET SIZE S/ IB Aq NH q .g 3 l" X 97" SHEET NUMBER PV-9 (H\-|NGPECTENT|REJOB8|TEFORHAZARDS ` ' /U-DRAW LADDER & ROOF ACCESS POINTS SKY LIGHT: YES I NO IF SO, HOW MANY: SERVICE LINE ENTRANCE: OVERHEAD I UNDERGROUND *IF OVERHEAD, DRAW POWERLINE ON PLAN SET AND PROVIDE APPROPRIATE WORK BOUNDARY CIRCLE WEATHER CONDITIONS: SUNNY OVERCAST LIGHT RAIN HEAVY RAIN FOGGY WINDY TEMPERATURE: IF WINDY, STATE WIND SPEED: LEAD INSTALLER IS TO CONDUCT A DAILY SAFETY BRIEFING AND THE INCLUDED CHECKLIST MUST BE COMPLETED WITH ALL NECESSARY LABELS PRIOR TO CHECK |FTHE FOLLOWING EQUIPMENT |SREADILY AVAILABLE (}N ALL BUNPR{}SOLAR INSTALLATION VEHICLES DMEACH JOB SITE: EYE WASH BOTTLE/SOLUTION DRINKING WATER FIRE EXTINGUISHER FIRST AID KIT NECESSARY JOB SPECIFICS LEAD INSTALLER SIGNATURE DATE CREW SIGNATURES: o a r PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 DATE: 08/26/2022 PROJECT NAME & ADDRESS Uj SHEET NAME JHA FORM SHEET SIZE ANSI B SHEET NUMBER Module power up to 410 W Module efficiency up to 20.2 % Lower LCOE & BOS cost Comprehensive LID / LeTID mitigation technology, up to 50% lower degradation Better shading tolerance �x T MORE RELIABLE Minimizes micro -crack Impacts ,, Heavy snow load up to 8100 Pa, enhanced wind load up to 6000 Pa* ,ham 1 if 25 industry Leading Product Warranty on Materials Years and Workmanship* 25 Linear Power Performance Warranty* Years 111 year power degradation no more than 2% Subsequent annual power degradation no more than 0.55% *Subject to the terms and conditions contained in the applicable Canadian Solar Limited Warranty Statement. Also this 25-year limited product warranty is available only for products installed and operating on residential rooftops in certain regions. MANAGEMENT SYSTEM CERTIFICATES* ISO 9001: 2015 / Quality management system 150 14001: 2015 / Standards for environmental management system I50 45001: 2018 / International standards for occupational health & safety PRODUCT CERTIFICATES* IEC 612151 IEC 61730 / CE FSEC (US Florida) / UL 61730 / IEC 61701 / IEC 62716 S * The specific certificates applicable to different module types and markets will vary, and therefore not all of the certifications listed herein will simultaneously apply to the products you order or use. Please contact your local Canadian Solar sales representative to confirm the specific certificates available for your Product and applicable in the regions In which the products vAll be used. CSI SOLAR (USA) CO„ LTD, is committed to providing high quality solar photovoltaic modules, solar energy and battery storage solutions to customers. The company was recognized as the No. 1 module supplier for quality and performance/price ratio in the IHS Module Customer Insight Survey. Over the past 20 years, it has successfully delivered over 63 GVV of -ford .al- ;nfor ainn.ple-re._rtonrstaua:or-Mcuu i. premium -quality solar modules across theworld, CSI SOLAR (USA) CO., LTD, 1350 Treat Blvd. Suite 500, Walnut Creek, CA 94598, USA I www.csisoiar.com/na I service.ca@csisolar.com ENGINEERING DRAWING (rnm) CS3N-404MS I I-V CURVES Rear View Frame Cross Section, A A 12 - 180 _ A- A _ n -�tj Y i 10 1e war .- 35 1 •'t 8-14a9 - Mouritiny '' '"` Lin ante m 6 6 i 4 4 t I .. _ � j 2 z { L. Mounflng Hole 0 5 10 15 20 25 30 35 40 45 50 55 60 5 10 15 20 25 30 35 40 45 50 55 60 `'- , 600 w/m' 45'C ..'2 998 -..9. 1.048 i < 2o0 w/m' _ ..35 -.... ELECTRICAL. DATA I STC* MECHANICAL DATA C53N 330MS 385Ma 39011VIs 395MS 000Aa 405NIS 41OMS Specification Data Nominal Max. Power (Pmax) 380 W 385 W 390 W 395 W SOW 405 W 410 W Cell Type Mono crystalline Opt. Operating Voltage (Vmp) 36.4 V 36.6 V 36.8 V 37.0 V 7,2 V 37,4 V 37.6 V Cell Arrangement 132 [2 X (11 X 6) ] Opt. Operating Current (Imp) 10A4 A1032 A10.60 10.68 A 0.76 A10,83 A10,92 A 1940 X 1048 X 35 Tom Dimensions _ _ Open Circuit Voltage (Voc) 43.7 V 43.9 V 44.1 V 44.3 V 4.5 V 44.7 V 44.9 V (76.4 X 41.3 X 1.38 in) Weight 23.4 kg (Si.6 Ibs) Short Circuit Current (Isc) 11.26 A11.32 A11.38 11,44 A 1.50 A11.56 A11.62 A Front Cover 3.2 min tempered glass Module Efficiency 18.7°fo 18,9% 19.2% 1.19.409.7% 19.9% 20.2% Frame Anodized aluminium alloy Operating Temperature -40°C - +85°C }Box IP68, 3 bypass diodes Max. System Voltage 1000V (UQ Cable 12 AWG (UL) Module Fire Performance TYPE 2 (UL 61730 1000V) Portrait: 400 prim (15.7 in) (+) ! 280 Cable Length mm (11.0 in) (-) (supply additional Max. Series Fuse Rating 20 A (including Connector) cable jumper. 2 lines/pallet); land - scope: 1250 min (49,2 In)* Application Classification Class A _ Connector T4 or MC4 series Power Tolerance 0 - + 10 W Per Pallet 30 pieces *'Under Standard Test Conditions (STC) of irradiance of 1000 W/info spectrum AM 1.5 and cell temperature of _ Per Container (40 HQ) 720 pl2ces * For detailed information, please contact your local Canadian Solar sales and technical representatives. ELECTRICAL DATA j NMOT* CS3N 38OMS 385FAS 390MS 395MS 400LIS 405MS 41OMS Nominal Max. Power (Pmax) 284 W 288 W 291 W 295 W 299 W 303 W 306 W TEMPERATURE CHARACTERISTICS Opt. Operating Voltage (Vmp) 34.0 V 34.2 V 34A V 34,6 V 34.7 V 349 V 35.1 V Specification_ Data Opt, Operating Current (Imp) 8.35 A &42 A 8.48 A 834 A 8.60 A 8.66 A 8.73 A Temperature Coefficient (Pmax) -0.34 %l *C Open Circuit Voltage (Vac) 41.2 V 41.4 V 41.6 V 41.8 V 41.9 V 42.1 V 11 4-13 V Temperature Coefficient (Voc) -0.26 % l °C _ _ Temperature Coefficient (Isc) 0,05 % / °C p Short Circuit Current (Isc) 9.08 A 9.13 A 9.18 A 9.23 A 9.28 A 9 33 A 9,37 A - - - * UndeOperatingHiOian oinal Module Operating Temperature ,NT), irradce 11 of 800 W/m-spettrum AM 1,5, ambient Nominal Module Operating _ .. p _._. Temperature 42 ± 3°C_. _ ... temperature 20-C, wind speed 1 m/s. PARTNER SECTION * The specifications and key features contained in this datasheet may deviate slightly from our actual products due to the on -going innovation and product enhancement CSI Solar Co., Ltd. reserves the right to make necessary adjustment to the information described herein at any time without further notice. Please be kindly advised that PV modules should be handled and installed by qualified people who have professional skills and please carefully read the safety and installation instructions before using our PV modules. CSI SOLAR (USA) CO., LTD, Jan. 2022 ( All rights reserved i PV Module Product Datasheet v2.9C25_F23J2_NA j i a r V 22171 MCH RD MANDEVILLE, LA 70471 PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN OS/26/2022 DATE: 08/26/2022 PROJECT NAME & ADDRESS 0 0 CO 7 t00 W J LL J W <^ Z Lt� LLJ LU F- p(ryry W VJ ry J W W W ® co = O7 Z li W N SHEET NAME EQUIPMENT SPECIFICATION SHEET SIZE ANSI B 11" X 17' SHEET NUMBER PV_12 Our newest 108 Microinverters are the industry's first microgrid-forming, software - defined microinverterswith split -phase power conversion capability to convert DC power to AC power efficiently. The brain of the semiconductor -based microinverter is our proprietary application -specific integrated circuit (ASIC) which enables the microinverter to operate in grid -tied or off -grid modes. This chip is built in advanced 55nm technology with high speed digital logic and has super -fast response times to changing loads and grid events, alleviating constraints on battery sizing for home energy systems, ax, W w Part of the Enprosse Energy System, iQ6 Series Microinverters integrals with the Enphare, IQ Battery, Enphrase, 10 Gatieway, and the Enphase Appmore ftahrg and analysis software, Connect Ply modules quickly and easily to 1Q8 Series Microinverters using the included Q-DCC-2 adapter cablewith plug-n-play MC4 connectors. lQ8 Series Micro inverierFredefires reliability standards with there than one miltror cumulative hours of power -an testing, eT,ablinganind,astr,/-Ieadinglirr�tedy4arranty of up to 25 years, IQ8 Series Isficromyerters, are UL Listed as PV Rapid Shut Down Equipment ar,,l conform with varicus regufat;ons, when Installed according to ton nufacturer's instructions- Q 2021 EnipmewEnergy. All rights reserved. Enphase, the Enphase logo, IQ8 micrionvert rs, andrather names are trademarks of Enphase Energy. Inc, Data subject to change, lQ83P-DS-00,32-(-)l-EN-L�3-2021-10-19 Easy to install Lightweight and compact with plug-n-play connectors Power Line Communication (PLC) between components Faster installation with simple two -wire cabling High productivity and reliability Produce power even when the grid is down More than one million cumulative hours of testing Class 11 double -insulated enclosure Optimized for the latest high- powered PV modules Microgirld-forming Complies with the latest advanced grid support Remote automatic updates for the latest grid requirement-. Configurable to support a wide range of grid profiles Meets CA Rule 21 (UL 1741-SA) requirements ITOMM Commonly used module pairings' W 235-350 235-440 Module compatibility 60-cex/120href-cell 60-cell/120 half -cell and 72- cell/144 half-cel! MPPT voltage range V 27-37 29-45 Operating range V 25-48 25-58 Min/max start voltage V 30148 30158 Max input DO voltage V 50 60 Max ErCcurrenh1mrsouleftol A 15 over,initage c iass DC port if DC part backfeed current my 0 PAJ array configuration W Ungrounded array; No adaftional DC side protection required; AC side protection requires max 20A per branch circ uft Peak output loceirs VA 245 300 Max continuous output power VA 240 290 Norisrah (L-L) volorge/rangey V 240/ 211- 264 Max continuous output current A to 1z NoTninaifteguency Hz 60 Exterided free uency range 50 - 68 Max units per 20 A (L L) branch circuit' 16 131 Total harmnic distortion Overvolitaqe class AC part III AC port barorfeeJ current M4 30 Power lactor aettr nx; 1.0 Grid -tied power factor (adjustable) 0.85 leading - o85 iagrgug Peak of ircrowy % 97,5 9T6 CEC weighted -efficiency % 97 97 Night-time power consumption Wr W 60 A r rb ie nt t a n T e r at u r a r a is V 400C to .600C (4cre P to 44 TF) Relative humbli ty range 4s, to I W, i c a n d e r,.s{ n g) DC Connector type MC4 Dimensions (HxWxD) 212 mm OX) x175 mrn leg") x 30.2 mrn 0.21 Weight 1,08 kg U38 I bs) Cooling Natural convection -na farts Approved forreet locations yes Acckenic norse at I rn 60,JBA Pollution degree Is D-3 Enctosure Class 11 aouble-insulised, corrosmn resetant polyrneric enclosure Enviran. catergory / twexposure rating NEMA Tye 6 / outdoor CA Rule 21 (UL 1741-SA), UL 62109-1, UL1741/IEEE1547, FCC Part 15 Class B. ICES-0003 Class B. CAN/CSA-C22.2 NO. 1' 07.1-01 Certifications This product is UL Lithe-das PV Rapild Shut Down Equipment andcanformswith NEC 2014, NEC 20TT arid NEC 2020 section 630.12 and C22,11-2018 Rare 64-218 Rapid Shutdresinar PV Systems. for AC and DC oDnducter% when installed according to manufacturer's instructions. (1) No enforced DC/AC ratios. See the compatibility calculator at https.//Iirk.eriphase,cor.n/ module-compatib(lity (2) Maximum continuous input DC current is 10_6A 13) Nominal voltage range can be extended beyord nomeral if radlyued by the Lftilfty.(4) Umus may vary. Refer to weal riscruh-a-ments to define the number of rucricinveners Per branch in your area. 108SP-DS- 0002-01-EN-US-2021-10-19 _­ X olar 22171 MCH RD MANDEVILLE, LA 70471 PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 DATE: 08/26/2022 PROJECT NAME & ADDRESS N31 < 0 L0 co Uj _j (Y) _j z W U) U) C) � 0 —1 Uj —5 0 T_ 0� LLI 2 0 Q0 zAl CY) 0- LO LLI CY) SHEET NAME EQUIPMENT SPECIFICATION SHEET SIZE ANSI B 11" X 17" SHEET NUMBER PV-1 3 n pr "t asci NI--,,'� E p Enphlase IQ I-) Co iner 4/4C X-IQ-AMl-240-4 X-IQ-AM1-240-4C LISTED X-IQ-AMI-240-4 To learn more about Enphase offerings, visit gil co _Bse iIC-f-1 a and irtecaipcl LIEIaa-edl se ,onsoiidi] Tes ir equilor en- i-toa s!righe, encics.lre an� sreairrtlines. micrIc.m.,rter s and Stnr,3go In` idllaC -)ns by provirfir,a a consiste-,,-.t, pre-lIvired solul ion f )r t -lesidential its)ratioIt offers up to four 2-pole MIPLI' 0I,-i-.UIts an- Evon BR, serips ou,sbar assemibly Includes Q Gateway for communication and control Includes Eniahaselclotile Connect cellular rmockor, included only with Q Combiner 4C includes solar shield to match Enphase IQ Battery aesthetics and deflect heal, Flexible neifictricnij supports Wi-FI, Ethernet, or cellular Optional AC receptacle available for PLC bridge Provides production metering and consurrption monitoring Centered mounting brackets support single stud mounting Supports bottom, back and side conduit entry Lip to four 2-pole branch. circurts fo, 9-40 VAC plug-in breakers (not included) 80A total PV or storage branch circuits Durable NR TIL-certified NENIA type 3R enclosure Five-year linnited warranty Tells years Abrat reimbursement program coverage Included for both the Q Combiner SKU's UL listed Enphase IQ Combiner 4/4C MODEL NUMBER lkiCombioe,4 [X-JQ,AM1,24u-4) IQ Coodoner4erah Eft. il-awl of Gated oaro-sntericilcuri board (ANS! IQ Systern Coriv orhar 2 and to deflect beat- 1,,, IX !Q AMI 24,; AC, In CO Er. AC of1-'-frpr,,j,u, IQ Caicvat, wt 7fa;Ir:uq u a Lc,rol (,12 20 - d d'i,) and l-orsuropn-i i-nonitwing fi-; 2 Include,, friplosI Mor,110,;onaect celicla, ncdam lCELLIVIOD"A-10 14"c'Sp-rc,"I'a oug-ano-troo, ridustro'-gitwe ceo modem -vii Slistems up w 60 US Car-rja, da,uco luz..I jnc me IS VII gl!i I siands, ivlbefa-.bcre A accc;i;a1c, r--c I clar ,ol„c, r- thct"03t 0, are- l ocrjd,,s a a Ier sid:l, nriiiiCq th, I C 6ifrt�, i are, Q SfFnm Cy-niciler and to de,...5:, ACCESSORIES AND REPLACEMENT PARTS "'not included, order seriaauflyt, Entienibip Communications Kit -- - ------- includes (dAfAS-Bf `01 -and CELL-NIGIDEM MI -06-SP-05 won 5 veir ScOot cars pout ic, CONIMSiCELLMOO EM PH 06 Enroonbs, sites CELLMODEM-le 1-06-SP-05 40 hased LTE-Ixll cellilhar ritudern, wren 5 year Syi,mt, daci plan CELLMODENI-MI -06-AT-05 as cased LTE M I cerular rnordionleth 5,,ew Ar&T data rdbri ;o c 'I --i -, olsak-r 21 DoIe, 10A Ezn-r sR?Iu ',ernc:'Dreaker, - ocle, 151A, Eu,,or 3R215 BEd U!, A 411t, '-rcul,breaker, 2pok., 21 WIK 1a 2P 2401 8 C,r,iui breaker, 9 noitt, 19A Er o 9R2. ,r f,Iii hoid down rr scIpoorl TaK ?CA 2P 2 U;V 13 Cc,cw; 9 no1c., 20A -,00t SR72rB all,. hoia-dr— k,z,-pPo,t EPLIC-01 P,`fine carrier (ccrumumobor brvig-e slor), qjantry - oille iwr5 XA S(XARSH:ELD 3 ,, e -ne't 3 S c" e: . tiil Q Co: It b; — 4, 4 XA, PLUG 120-3 Accessory oicepw6slo' Power Line Carr'-fr in d) Cormerer 4/4C -cEro C W) XA ENV PCBA,3 Q Gldn,4ay pr:rlle"', c-c"at hoaro ror X fIQ NA 140 125A HoW sown kit to, Eacar, edicurl dreakerenth croeori ELECTRICAL SPECIFICATIONS Riorind; i3,ctf3in f ltngo Eaton BR series susbaf rating ol't, Max, condinuous Current rating, , "- Clo) "Pu! fir Por,'st"Ifors, Kfii,, ',so ct-.�ail,at ng �nnlp,- Branch cwtaLw ysorarzind/ar scarage) M,I` "' to-ercin. facnq rlp I,)n l3l Envoy b, oiAin- Pr-vluc,jun -P1-,.-q T continuous do,/ 12024l) /,vc� 0 Hz 125 A 6'1 A 64A Up t, four 2- poke Eaton BP sanas Disiriouted Generalmn iDG) breakers crdi "not irodlaed, BOA 10 n,-3U,1-1nT-c jilrra,,cc " 95A "'Irr 10 cAo,',cay wrlakl- I GA or 15A ' rating Gs' 'SIomensEaron included ')WI A -,G!.,d core,) an-- "It') Iu Connumiumn morfooring I T (CT200 SPLI APfo, of 200 A apilt rore current fransf rrne, s MECHANICAL DATA 4-Ti, x'1's -8 c'r (1--4-,-o­,-' A 19, 5"--x-6 6' '1), H, ris,hi, Is --'! 66(5-3-5- llm- ) wtn 'o,"gIin 7.5a 55 0 s' Ambienz Tempe lanin, range -401 ' to +46' C (-40' to 115': Fit Cooling Nuoural cocecfiran, pins hvio shmad Erwroure environmental otinig Outdoor, NATL-csinified, NEIVIA type 3R, porywartionale confoructor. 2 ii A ro SO A otv, ike, npt` a I A in f op pe r -- r di lito, of, A brexcer id,-3,ch lnpu' 4 -.-- 1 '0 -NG c0pr)or Main lug cembired owplrt Id , ) 2,-', ANC cnpirer • wenlffa; and ,graurrol 14 �o, 1, C crope,T cord,jCtorc Always frolow itorw imdeoantr f,,, condrrnnr cn7iriq Altiord,,, To 2000 icaoirs (6,560 feeir INTERNET CONNECTION OPTIONS Integrated Wi-Ps BOB 11I Ccdukn, C'Ll N1,1DEM N1 1 06 oP 05, C'--I-100111-m M, ut, A T 05, C. T. I ce r c-B -,a note trat an Frpois- inrider-i s n--gr ren i0i ail ---roe-In instedulon3 Ethernet -Optional, 802S. Qua 5E (or Cat 6) UT A Ethernet cribie (bar Included) COMPLIANCE Cc-ni-b,:-I-rer - , - - --- U- I -C, C--S, -A, -C-2-2 ]2- N--o-71-0-7-1 T, - A -7, '&F s7P —ar t, 11, 5-, p-I a' a a 8, ICES 7Gs Produr€cemetering: ANSI C12,20 accuracy class 0,5 (PV pioductionr Consumption rrietering: accuracy class 2,5 We-av no ENPHASE !=ENPHASE To learn more about Enphase of fenn gs, visit iinphasecond lfeo� red "J 22171 MICH RD MANDEVILLE, LA 70471 PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 DATE: 08/26/2022 PROJECT NAME & ADDRESS < 0 U') C11) CY) U.] LL LL < z W U) C) � C) W —5 0 W 2 C.0 z110) 0') CL < U') III co IN SHEET NAME EQUIPMENT SPECIFICATION SHEET SIZE ANSI B 11" X 17" SHEET NUMBER PV-14 P/N DESCRIPTION ENDCLAMP PRO PRO SERIES MID CLAMP 1'12 30mm to 53.mm MODULE FRAME I� �1 LL -I DESCRIPTION s FOR BONDING END AI CLAMP REFER TO SHEET SM-PO5 '/ " 17 V ; ES - REFER TO SHEET S -P05 BONDING SM MID CLAMP BONDING SM END CLAMP PRODUCTUNIRLINE:I * I���II�p���ri� �II I� II IIII��III��MV"NG NOT TO SCALE ALL DIMENSIONS ARE ALL DIMENSIONS ARE ,, S tt�"� I� I�� �; ��������I���I�� M -Own PAR I &ASSEMBLY1411 BROADWAY BLVD. NEIIIIIII I IIII III r o gltmo`1411 BROADWAY BLVD. NE BONDING TOPmt uu9lgl pni ool'wI �nln poilir, PHONE, 505.24,2.6411 CLAMPS mm u 22171 MCH R® MANDEVILLE, LA 70471 PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 DATE: 08/26/2022 PROJECT NAME & ADDRESS o CM ui LLL z ct' U —, Lu 0 W w co SHEET NAME EQUIPMENT SPECIFICATION SHEET SIZE ANSI B 11" X 17" SHEET NUMBER PV-15 PART TABLE P/N DESCRIPTION _ 004085M FLASHLOC COMP KIT MILL, 20 PACK 004085D FLASHLOC COMP KIT DARK, 20 PACK T) SS LAG BOLT W/ SS EPDM BONDED WASHER SS SERRATED T-BOLT SS SERRATED FLANGE NUT—� FLASHLOC BASE ' MILL OR DARK q1 � - �. 183 MC3C}L?LE FRAME f i �r 1k i 9� t U NG 3iZ y` f a c g�6sr - END CLIP t_7;$FP TRIM i DETAIL A v DETAIL B TRIM END CLIP TRIM MID CLAMP TRIM CONNECTION Vn it PART # TABLE P/N DESCRIPTION LENGTH «A 20 l SM TRIM DIRK 008025S SM TRIM END CLIP PRODUCT LINE: LARMOEINT DRAWING NOT TO E PRODUCT LINE: SOLARMOUNT DRAWING NOT TO SCALE ' ALL DIMENSIONS ARE + — — — -- ALL DIMENSIONS ARE DRAWING E: PART & ASSEMBLY NOMINAL Act DRAWING TYPE: PART DRAWING NOMINAL � 1411 BR WAY BLVD, NE ` 1411 BROADWAY BLVD. NE e ALRK,XWJE, NM 87182 DESCRIPTION- SM T END P PRO ui PROTECTED BY ALBUQUERQUE, NM 87102 USA DESCRIPTION: FLASHLOC COMP KIT PRODUCT PROTECTED BY =E: 5.2416411 ONE OR MORE US PATENTS PHONE: 505,242.6411 W — ;ONE OR MORE US PATENTS MUNMAC;COM REVISION DATE: '9/27/2017 WWW,UNIRAC.COM REVISION DATE: � 10/3/2019 _.__.._._.__..._ ... —._ .. KCAL NOTICE SHEET _ LEGAL NOTICE SHEET ' Solar 22171 MCH RD ANDEVILLE, LA 70471 PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 DATE: 08/26/2022 PROJECT NAME & ADDRESS +:y) W J_ W Lli r U J LLI — w LUco w N SHEET NAME EQUIPMENT SPECIFICATION SHEET SIZE ANSI B 11" X 17" SHEET NUMBER PV-16 881'U N I RAC FLASH LOC FLASH LOC ME BETTER SOLAR STARTS HERE INSTALLATION GUIDE FLASHLOC iS the Ultimate attachment for composition shingle and rolled comp roofs. The all -in -one mount installs fast — no kneeling on hot roofs to install flashing, no prying or cutting shingles, FIG pUlling nails, Simply drive the 0 2D lag bolt and inject sealant into the base, FLASHLOC's patented TRIPLE SEAL technology preserves the roof and protects the penetration with a per uanent pressure seal. Kfitted 'with lag bolts, sealant, and hardware for maxinival convenience-, Don't just divert water, LOC it out! Wiv PROTECT THE ROOF i,Jt tin-, i dail; - LOG OUT WATER HIGH-SPEED INSTALL e­ -hid:,fl,jrkiEl 1 i J r ,io i .3iEif SP3 �3P 13 ,Mdl i_�f­�;�'­;Ji l'id n . ,Isiiven a a SON Nunn U N I RAC BETTER SOLAR STARTS HERE PRE -INSTALL - Sil,av-1131k forafl�qt moss,-,,[,-'hmssis, On sh'no' rooke fs, ifnap � 1--,"4­be1ovuP,h ppe do,, of shliiiIe course, niu Lle riffipz-,and war sftti-,hmelid At eac!'f ln;cilknfl, aij "� 7/32" Q:F' hoe ("18"din olt sflrfo�-_e cf, ,dirt, debrio,,j, anc", uf, hien, filplot I 0:e' *t�eadqnl sr)Kf� 1 10!Jfl,per st, S-1'em inailil w.ei,­ICsflons V'Ai,�;, i r l"', S r os -_3­ rat. not ? it STEP 1: SECURE e FLASHLOC cvabo oil slolpe6rn Ahp, ifi-icatoi niaii on sidos" of K -d, la'a bolT fif d se�-flinn a-, h-, throiu�--h FLASH! 0' fito P W Rnount "fith Ghalo .'file, pad if [_,j hole, Orive la� until nio nit is hedd firmly i, )1,, a. iT I I t I- P T' ik I , il if i o C L)i in Ulf! if expaind boyffnd 1h,-­ edom 0`� th-", m0--i, WH prore, to r tis aplh �ed. qle, STEP 2: SEAL if Jept tin " liealafJ exits both am 1,� 'flontinuc arfav installat 01', attach nil rods to ongunts vvith projided T-bolts, Nh 'ver p or Vej,ftsl 0en FLASHLOG is Installed o q) bet�sioejj � �Iis of t&l N: gaplifloint silth seal'ant betisieen miount and upslope edge of shingle course. Us', only proviise= sealuL z C7 .- 1, zl, ol a r 22171 MCH RD MANDEVILLE, LA 70471 PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 DATE: 08/26/2022 PROJECT NAME & ADDRESS < 0 LO M CY) Lli J < z LU LLJ F- 0 UJ 0 LLJ z CY) 0) < LID UJ co N SHEET NAME EQUIPMENT SPECIFICATION SHEET SIZE ANSI B 11 " X 17" SHEET NUMBER PV-1 7 BONDING SPLICE BAR y}t}} 1/ Yf 411 TYPICAL SPLICE BAR DETAIL 2"-� 1411 BI1WAY BLVD. NE AtBUQUERQUE, W4 87102 USA PFM: 505,2416411 VMMUNIRAC C94 5/36--18 TYPE E THREAD CLITTING SCREWS INCLUDED NW-ITE T T ILY 2 S E USED AT AN EXPANSION JOINT. E SPLICE BAR DOES NOT BOND ACROSS AN EXPANSIONJOINT. SEE INSTALLATION GUIDE FOR INSTRUCTION. N. IIIIIIOII 17 DRAWING NOT SCALE � I I, �p � � ALL DIMENSIONS ARE IIII��J I�I�II I�� IIIIIII IIIIII� M 1. =•y it 1� M `' '1 '' �' NOMINAL •II *:.fig) x I �f 11 D! BAR PRO SERIES 8/23/2018 LEGAL NOTICE �1 no ■ 0 0 0 0 1/2 i5p xs " Fr tt n :-x a� L7RILLIN,G SCR.INCLUDED TYPICAL EXPANSION JOINT DETAIL PLICE BAR SERRATED CLR 1411 BR STAY BLVD. NE AaMERQUE, NM 87102 USA ESE: 505.2416411 WVkUNIRK.0014 NOTE. THAT ONLY 2 SCREWS ARE USED AT AN EXPANSION JOINT. THE SPLICE BAR DOES NOT BON ACROSS AN EXPANSION JOINT. SEE INSTALLATION GUIDE FOR INSTRUCTION. �1411 �11 ��I I�hSOLARMOUNT i DRAWINGNOT TO SCALE ALL DIMENSIONS ARE •i �'PART � ASSEMBLY BONDING ;r C BAR �l as REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 DATE: 08/26/2022 1 PROJECT NAME & ADDRESS > o Lo � ui J r'a LL z Q_U=� W (D i- `+. m W SHEET NAME EQUIPMENT SPECIFICATION SHEET SIZE ANSI B 11" X 17" SHEET NUMBER PV-1 S -20 X ' /4- SS HEX HEAD BOLT V4" FLAT WASHER Yet 1 Asa -/4--20 SS FLANGE NUT BOTTOM CLIP m loom P,00,0�0001 PART # TABLE P/N I DESCRIPTION 302000C I SM14D BOTTOM CLIPS W/HDW CLR -------- IN p PRODUCT LINE- SOLARMOUNT HD DRAIMNG NOT TO SCALE w so ALL DIMENSIONS ARE NT HD an RAC DRAWING TYPE: PART & ASSEMBLY NOMINAL 1411 BR%,DWAY BLVD, NE A[BUQUERQUE,NM87102USA DESCRIPTION- BOTTOM CLIP PRODUCT PROTECTED BY PRO r:R RE LJS PA ORE NOTICE LEML I REVISION 7 GAL NOTICE RME: 505.242.6411 ONE OR MORE LIS PATENTS -%V.UN1Wk0M Emw�—m _j as '/I- SOLT LOCATION -\ %- BOLT LC>(--,ATION P/N DESCRIPTION_ LENGTH SM RAIL 132" MILL ■ I am= IM RAIL 2W SM RAIL 240' CLR SM RAIL 240- DRK U N I RAC as 1411 BROADWAY BUVD, M� XRf,UWAf, NM 87102 USA PHOPE,'505242,6411 WWWUNIRACCOM MAWING NOT TO SCALE ALL DIMENSIONS ARE NOMINAL PRODUCT PROT ED BY ONE OR MORE US PATENTS LEGAL NOTICE an A 'Solatl 22171 MICH RD MANDEVILLE, LA 70471 PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 DATE: 08/26/2022 PROJECT NAME & ADDRESS < 0 u') (y) co ui -j -j U- < z LU C6 0 of c) LIJ i�5 0 0� LLI ry 0 cr C.0 z cy) cy) a- < u') ui cy) N SHEET NAME EQUIPMENT SPECIFICATION SHEET SIZE ANSI B 11 " X 17" SHEET NUMBER Pv-1 9 rl- - -- PRODUCT I TNE- --1 DRAWING NOT TO SCALE ALL DIMENSIONS ARE G TYPE: NOMINAL 9/27/201 1 1 B CLAMP 30mm to 32mm Module Thickness (L18- to L26') 2 E CIAMP 50mm to 5 imm Module Thickness (L97' to 2XG") PART# TABLE SM ENDCLAMP 6 CLR AL SM ENDCLAMP C CLR AL SM ENDCLAMP C DRK AL SM ENDCLAMP D CLR AL SM ENDCLAMP D DRK AL SM ENDCLAMP f SM ENDCLAMP E DRK AL SM ENDCLAMP K CLR AL SM ENDCLAMP K DRK AL C CLAMP 33mm to 36mm Module Thickness (1.30- to L42-) rompiffsporm" r1lumlimmm 38mm to 40mm Module Thickness (1.50'to 1.57") rmariampalmw 45mm to 47mm Module Thickness 39mm to 41mm Module Thickness (1.77' to 1.95') (1,54- to 1,61-) V. 3/16 1" TYPICAL END CLAMP DETAILS PRODUCT LINE: SOLARMOUNT DRAMING NOT TO SCALE W ALL =DIMENSIONS ARE d"UNIRAC DRAVIING TYPE- PART DETAIL NOMINAL 1411 ER 'AY BLVD. NE END CLAMPS - ER{ E, NM 87102 USA DESCRIPTION- JP'ITING J(( PRODUCT P I -Ri TOP MOUNTING PHONE 50 .242. 11 L ONE OR MORE US PATENTS WVNHNTWCL,C0'f41j LREVISIOLNDATE. 9/27/20,1171 LEGAL NOTICE on i a r 22171 MCH RD MANDEVILLE, LA 70471 PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 DATE: 08/26/2022 PROJECT NAME & ADDRESS T- -4:r < 0 Lf) CY) CIO LLJ LL < LL Q. LLJ U) LLJ —j U) 0 =J LLJ �5 0 T w LU 75 w 0 z o) 0- < U-) Uj CY) N SHEET NAME EQUIPMENT SPECIFICATION SHEET SIZE ANSI B 11" X 17" SHEET NUMBER PV-2 "Fuse holders and terminal blocks added in the field must be UL listed or recognized and meet 600 VDC 30 AMP 110C for fuse holders, 600V 50 AMP 90C for rail mounted terminal blocks and 600 V 1.75AMP 90C for Power Distribution Blocks, Use Copper Wins Conductors, SclaDeck Model SD 0783 Available Models, Model SD 0783 - (3- fixed Din Rail) Model SD 0766 - (6" Slatted Din Rail) SoIaDeck UIL 1741 Combiner/Enclosures Models SD 0783-41 and SD 0786-41 are labeled and ETL listed UL STD 1741 according to the UL STD 1741 for photovoltaic combiner enclosures.. Max Rued - 60OVDC, 120AMPS Nadel SD 07 3-41 " Fred Din Rail fastened using Norlock System **Typical System Configuration 4- Din Rail Mounted Fuse Holders 60OVDC 30 AMP 1- Power Distribution Block 60OVDC 175AMP 1- Bus Dar with UL lug Model SD 07 6-4f 6" Slatted din Rail fastened using steel studs **Typical System Configuration 4- Din Rail Mounted Fuse Holders 6OOVDC 30 AMP 4- Din Rail Mounted Terminal Blocks Bus Bars with UL lug conduit or fittings, base is center dimpled for fitting locations. Model Sly 078341, wired with Model SD 0786-41 spired with Din Rail mounted fuse holders, Din Rail mounted ;use holders, bus bar and power distribution terminal blocks and taus bars. black. • Heimstead • r 703 rt Forproduct informationin • s o,,oiar 22171 MCH RD MANDEVILLE, LA 70471 PHONE: 9152011490 REVISIONS DESCRIPTION DATE REV INITIAL DESIGN 08/26/2022 DATE: 08/26/2022 PROJECT NAME & ADDRESS 0S � U U') M W J Q Lt_ Z W {) W U -i III - W 2 cr_ Z o) 0- <C m W N SHEET NAME EQUIPMENT SPECIFICATION SHEET SIZE ANSI S 11" X 17" SHEET NUMBER PV-21 —�