18-20576 - Laserfiche WebLink

Browse Search

Estimate ESTIMATE # 9841 J"LJL n 9 DATE 12/3/2018 r.�a i $ iX1%t�1 C)rX Inc. eWe ' ve Gat You Caufared CB Roofing Construction inc. 501 South Falkenburg Rd Ste D-12, Ph 813-569-6930 Tampa Florida33619 sales@cbroofingconstruction.com CCC1330088 www.cbrc.co latent defects in materials and accessories supplied. Company shall not be responsible for rework required as a result of the acts or errors of others. 10. Liens. Should default be made in payment of this Agreement,alien will be placed on the property and charges will be added from the date of substantial completion at the maximum rate allowed by law, If placed in the hands of an attorney for collection, Customer will pay all attorney and legal fees. 1 1. Entire Agreements. This Agreement constitutes the entire Agreement and understanding of Company and Customer relating to all of the subject matter herein,and supersedes all prior agreements,arrangements and understanding,written or oral between the parties concerning such subject matter. ANY REPRESENTATION, STATEMENTS, OR OTHER COMMUNICATION NOT WRITTEN IN THIS AGREEMENT, OR MADE IN WRITING PURSUANT THERTO, ARE AGREED TO BE IN INVALID AND NOT RELIED ON BY EITHER PARTY AND DO NOT SURVIVE THE EXECUTION OF THIS AGREEMENT. 12. Reformation/Severability Company and Customer intend and agree that if a court of competent jurisdiction determines that the scope of any provision ofthis Agreement is too broad to be enforced as written,the court should reform such provision(s) to such narrower scope as it determines to be enforceable. Company and Customer further agree that if any provision of this Agreement is determined to be unenforceable for any reason, and such provision cannot be reformed by the court as anticipated above,such provision shall be deemed separate and severable and the unenforceability of any such provision shall not invalidate or render unenforceable any of the remaining provisions hereof. 13. Time to Complete. CBRC will have 90 days from the signing of the contract and or signing of the NOC or availability of material or weather delays whichever is later to complete the project. 14. Chapter 558,Florida Statutes,contains important requrements you must follow before you may bring any legal action for an alleged construction defect. Sixty days before you bring any legal action, you must deliver to the other party to this contract a written notice,referring to the chapter 558, of any construction conditions you allege are defective and providing such person the opportumtyty to inspect the alleged construction defects and to consider making an offer to repair or pay for the alleged construction defects. I�ou are not obligated to accept any offer which may be made. There are strict deadlines and procedures under this Florida law which must be met and followed to protect your interest. 15. Florida homeowners' construction recovery fund: Payment may be available from the Florida Homeowners' construction recovery fund if you lose money on a project performed under contract,where the loss results from specified violations of Florida law by a licensed contractor. For information about the recovery fund and claim. Contact the Florida Construction Industry Licensing Board at the following telephone number and address: Division of Professions Construction Industry Licensing Board 1940 N.Monroe St.Tallahassee FL 32399 Phone: 850.487.1395 Email:call.center@dbpr.state.fl.us 16. NOTICE OF FLQI II� S CONSTRUCTION LIEN LAW ACCORDING TO FLORIDA'S CONSTRUCTION LIEN LAW (SECTION713.001-713.37 FLORIDA STATUTES)''THOSE WHO WORK ON YOUR PROPERTY OR PROVIDE MATERIALS A B SERVICES AND ARE 7NOT PAID IN FULL HAVE A RIGHT TO ENFORCE THEIR CLAIM FOR PAYMENT AGAINST YUR PROPERTY. THIS CLAIM IS KNOWN AS A CONSTRUCTION LIEN. IF YOUR CONTRACTOR OR A SUBCONTRACTOR FAILS TO PAY SUBCONTRACTORS SUB- SUBCONTRACTORS OR MATERIAL SUPPLIERS THOSE PEOPLE WHO ARE OWED MON MAY LOOK TO YOUR 1ROPERTY FOR PAYMENT' EVEN IF YOU HAVE ALREADY PAID YOUR CONTRACTOR IN FULL. IF YOU FAIL TO PAY FOUR CONTRACTOR, YOUR CONTRACTOR MAY ALSO HAVE A LEIN ON YOUR PROPERTY. THIS MEANS IF A LIEN IS FILED YOUR PROPERTY COULD BE SOLD AGAINST YOUR WILL TO PAY FOR LABOR,MATERIALS OR OTHER SERVICES THAT YOUR CONTRACTOR OR A SUBCONTRACTOR MAY HAVE FAILED TO PAY. TO PROTECT YOURSELF YOU SHOULD STIPULATE IN THIS CONTRACT THAT BEFORE ANY PAYMENT IS MADE YoN CONTRACTOR IS REQUIRED TO PROVIDE TO YOU WITH A WRITTEN RELEASE OF LIEN FROM ANY PERSON OR COMPANY THAT HAS PROVIDED TO YOU A"NOTICE TO OWNER" FLORIDA'S CONSTRUCTION LIEN LAW IS COMPLEX, AND IT IS RECOMMENDED THAT YOU CONSULT AN ATTORNEY. How To Accept Estimate#9841 Total amount$8,499.00 To accept this quote,please call or email us using the details at the top of the page. Thank you for your business, have a great day!