19-21588 - Laserfiche WebLink

Browse Search

OSHA regulations require that"all employers provide information to their employees about the hazardous chemicals to which they are exposed".Provide a list and MSDS(Material Safety Data Sheets)for all of the hazardous chemicals known by your firm to be present on this protect created btiyorgpe of Work.Label all hazardous chemicals properly. The label will list the contents of the container, appropriate hazard warnings and name and address of the manufacturer, importer, or other responsible party. Provide a material safety data sheet for each hazardous chemical present at the job site. Hazardous communications programs and safety data sheets will be located at the construction trailer. ARTICLE 10 DISPUTE RESOLUTION: It is mutually agreed that all disputes between Contractor and Subcontractor arising in connection with this Agreement that may Involve disputes between Contractor and Owner, shall, at the sole election of Contractor, be resolved in accordance with the dispute resolution provisions of the principal contract between Contractor and Owner. All disputes between Contractor and Subcontractor arising in connection with this Agreement, that do not Involve disputes between Contractor and Owner,shall,at the sole election of Contractor,be subject to binding arbitration in accordance with the Construction Industry Rules of the American Arbitration Association.This binding arbitration shall take place in Tampa, Florida. In any dispute resolution proceedings arising out of or relating to this Agreement, the prevailing party shall be entitled to an award of its costs and reasonable attorneys'fees, including all such costs and attorneys'fees incurred on appeal. ARTICLE 11 DELAY: Subcontractor shall be responsible for any damages for delay attributable to Its Work. A reasonable time extension will be provided to Subcontractor for delays beyond its control. Subcontractor agrees bD make no claim for damages or loss for delay In performance of the Work occasioned by any acts and specifically agrees that such damages or loss as shall be fully compensated for by an extension of time to complete the performance of the Work. Sub- Contractor shall be responsible for any damages suffered by the Owner and Contractor arising out of defective work performed by Sub-Contractor or any other material breach of this Agreement by the Sub-Contractor. ARTICLE 12 TERMINATION FOR CONVENIENCE: Contractor reserves the right to terminate this Agreement at any time, for Contractor's convenience, by providing no less than seven (7)calendar days written notice to the Subcontractor. In the event this Agreement is terminated for Contractor's convenience, Subcontractor shall be entitled to payment for all work performed through the date of termination. However, Subcontractor shall not be entitled to any additional compensation from the Contractor, Including,without limitation,lost overhead or profit on Work not performed by the Subcontractor. ARTICLE 13 ENTIRE AGREEMENT: This Agreement constitutes the entire understanding of the parties relating to the Work and supersedes any prior proposals or agreements,written or oral.This Agreement cannot be changed or modified orally.Any change or modification to this Agreement must be made by way of a written change order or amendment signed by both Contractor and Subcontractor. In witness whereof,the parties have executed this Agreement,the day and year first written above. Electrical Contractor Services.Inc. J.O.DeLotbo&Sons,Inc. SUBCONTRACTOR(FIRM NAME) BY: S Executive Vlce-President Tile or Positioh Title or Position Subcontractor's Federal Tax ID Number GCs license q: CGCOSS906 Note: PLEASE EXECUTE AND RETURN ONE(1)COPY TO OUR OFFICE IMMEDIATELY. Dann r;