|
PRICE CALCULATIONS. If this Contract includes Goods and related Installation Services sold by unit of measurement, such as
<br /> per square foot, the Price may include more Goods than the actual measurements of Your project area. The Price includes the
<br /> total amount of Goods required by Lowe's to fulfill the Contract(including surplus materials and overages) (together the
<br /> "Estimated Product")and the Installation Services required based upon this total amount of Goods. For instance, a 120 square
<br /> foot room may require 140 square feet of carpet, and the Price would include Installation Services based upon the 140 square
<br /> feet of carpet. The total amount of Estimated Product is based upon the total Goods recommended by the Installer, based on the
<br /> Installer's assessment of unique characteristics of Your project. If any usable Goods are left over, Lowe's may, at its discretion,
<br /> initiate a Price adjustment. Lowe's will not adjust the Total Contract Amount for the related Installation Services. By signing this
<br /> Contract You acknowledge You are aware of Your project area measurements and the amount of Estimated Product, and that the
<br /> Estimated Product may exceed Your actual project area.
<br /> LEAD SAFE INFORMATION. Federal and applicable state laws require that You be provided with a lead hazard information
<br /> pamphlet such as the Renovate Right: Important Lead Hazard Information for Families, Child Care Providers and Schools. By
<br /> signing this Contract, You acknowledge having received a copy of this information pamphlet before work began informing You of
<br /> the potential risk of the lead hazard exposure from renovation activity performed in Your dwelling unit or facility. A copy of the
<br /> pamphlet is available at the following website: https://www.epa. ov/sites/production/files/documents/renovaterightbrochure.pdf.
<br /> ARBITRATION AGREEMENT. This Contract provides that You and Lowe's will resolve all claims by BINDING ARBITRATION.
<br /> You and Lowe's GIVE UP THE RIGHT TO GO TO COURT to enforce this Contract(EXCEPT for matters that may be taken to
<br /> SMALL CLAIMS COURT). A NEUTRAL ARBITRATOR will determine Lowe's and Your rights and NOT a judge or jury. You and
<br /> Lowe's are entitled to a FAIR HEARING. BUT the arbitration procedures are SIMPLER AND MORE LIMITED THAN RULES
<br /> APPLICABLE IN COURT. Arbitrator decisions are as enforceable as any court order and are subject to VERY LIMITED REVIEW
<br /> BY A COURT. FOR MORE DETAILS: Review the sections titled ARBITRATION AGREEMENT, WAIVER OF JURY TRIAL AND
<br /> WAIVER OF CLASS ACTION ADJUDICATION found in the Terms and Conditions of this Contract.
<br /> PHOTO RELEASE. By signing this Contract, You grant to Lowe's, its representatives, and Installer the right to take and use
<br /> photographs, videos, or other representations of the Project Address before and after the Installation Services and all work
<br /> performed at the Project Address related to this Contract(the"Content"). Lowe's irrevocably keeps all rights (including the
<br /> copyright), title, and interest in the Content for use in all markets and media, worldwide, in perpetuity. Lowe's can use the Content,
<br /> in any form or medium, internally for any purpose (e.g., customer service, planning, and claims).
<br /> TERMS AND CONDITIONS
<br /> 1. COMMON DEFINITIONS. Capitalized terms used in this Contract will either have the following stated meanings or will be
<br /> defined throughout the Contract.
<br /> a) "You", "Your(s)", and "Customer" all mean the person executing this Contract to purchase Installation Services.
<br /> b) "Goods" means the physical items You are purchasing in connection with the Installation Services. A list of the Goods
<br /> appears on the Estimate.
<br /> c) "Installation Services" means the work, labor, and other services necessary to install the Goods. Some examples of
<br /> Installation Services include delivery, handling, return, and selection and placement of Goods.
<br /> d) "Installer" means the independent contractor Lowe's arranges to perform the Installation Services. Installer will be
<br /> licensed when legally required, and will direct, control, and perform the Installation Services directly or through its employees,
<br /> agents, and subcontractors using tools and equipment Installer provides. Lowe's does not employ Installer, its employees, or its
<br /> agents or subcontractors.
<br /> e) "Lowe's" means Lowe's Home Centers, LLC, a North Carolina Limited Liability Company located at 1605 Curtis Bridge
<br /> Road, Wilkesboro, NC 28697. Lowe's Employer Identification Number is 56-0748358.
<br /> 2. SCOPE.This Contract is between You and Lowe's for the purchase of Goods and Installation Services. Lowe's does not
<br /> perform Installation Services, but arranges for Installer to do so directly or through Installer's employees, agents, or
<br /> subcontractors. Installer is an independent contractor and is not under the supervision or control of Lowe's. Installation Services
<br /> do not include architectural or engineering services. Installer will complete Installation Services, subject to any changes, in
<br /> substantial conformance with the Merchandise and Installation Summary. Lowe's reserves the right to terminate or rescind this
<br /> Contract if Lowe's decides that any portion of the job is beyond the scope of the Installation Services that Lowe's originally
<br /> contemplated.
<br /> 3. CHANGE ORDERS. Any changes to the Goods and/or Installation Services, including but not limited to changes necessitated
<br /> by undisclosed, unidentified or unforeseen conditions on the site ("Undisclosed Conditions"), are subject to a written Change
<br /> Order,which shall specify the change in scope and any adjustment to the Total Contract Amount, which will be reflected in the
<br /> Due Upon Completion payment. Neither Lowe's nor Installer shall have any obligation to remediate any such conditions and, at
<br /> its discretion, Lowe's may immediately discontinue the installation or ask for a Change Order. Neither Lowe's nor Installer will
<br /> remediate any mold, asbestos or lead-based paint and are not responsible for any delays caused by events beyond either party's
<br /> control, including but not limited to acts of nature, governmental actions, delivery delays, or delays caused by third parties, labor
<br /> strikes, project financing, incorrect information provided by You or Your non-compliance with this Contract.
<br /> 4. GOODS. Title to Goods does not pass to You and remains the property of Lowe's until Goods are installed in Your home,
<br /> Doc ID: 1e3b2d1413ede5a3b385514021715c4a46b02783
<br />
|