|
TETiMS: Th�s Nroposal shall be considered to be an accepted and a valid binding Contract between Neumann Roofing,LLC`-(herein referred to as"Contractor"and the"Customer"and/or
<br /> "Owner"upon execution of this Contract by all parties and shall constitute the entire agreement be[ween the parties. The ConVact is the entire agreement between the parties and supersedes all
<br /> prior agreements between the parties.Any alterations,modifications or amendments to this Contrac[shall not be binding unless in writing and signed by all parties. Until executed,Contractor
<br /> I may withdraw this Proposal at any time.
<br /> , The DEPOSIT/PAYMENT schedule for your roof will be as follows unless noted otherwise here: A � %deposit is to be paid within �'� prior to the
<br /> commencmg work;another V °/draw is due after sub-roof is completed,with remaining balance due and PAYABLE UPON COMPLETION. Any variations to the payment
<br /> schedule noted here supercedethe preceding base schedule:
<br /> Contractor shall be entitled to deduct any and all prepaid costs,recording expenses,expenses associated with recording the Notice of Commencement,all permitting expenses and any and all
<br /> other expenses incurred by Contractor in the event of cancellation of this contrac[prior to compietion,in addition to any and a Il other remedies associated with the cancellation of this contract
<br /> by the Customer and/or Owner.
<br /> i,
<br /> Contractor shall be responsible to Customer and/or Owner for obtaining any and all licenses and building permits which are legally required to perform the Contract Contractor shall also be
<br /> responsible to Customer and/or Owner for the Contract being performed in compliance with all applicable safety rules and all existi�g building codes,zoning ordinances and other laws. If a
<br /> charge occurs to any applicable safety rule,building code,zoning ordinance or other law which requires additional goods and/or installation services to perform the Contract,Customer and/or
<br /> Owner agrees to pay Contractor the wst and reasonable profit of such addrtional goods and/or services.
<br /> Payment shall be due within P _of completion of the work to be completed under the terms of this Contract. A notice to Customer and/or Owner shall be
<br /> recorded upon execution of this Contract. Failure to tender a payment pursuant to the terms of this Contract may subject Customer and/or Owner's property[o applicable liens by Contractor.
<br />� In the event that any obligahon hereunder is not paid in accordance wi[h the terms set forth above,interest shall accrue at[he rate of 1.5%per month unti]paid in full. IN the event it becomes
<br /> necessary to seek remedy for this Contract or collect sums due hereunder through the efforts of an attorney,the Customer and/or Owner agrees to pay all costs and expenses of such dispute
<br />� resolution,collection or enforcement(weather or not incurred before the suit is initiated,beFore judgment is obtained or upon appeal)including,but not limited to all costs and reasonable
<br /> attomey's fees,including appella[e attorney's fees.
<br /> The parties stipulate and agree that Pasco County,Florida shall be the venue of any and all litigation associated with this convact. This Agreement shall be governed by,and shall be construed
<br /> I and enforced in accordance with,the laws of the State of Florida without regard to the application of its conflict of laws rules. In the event of a breach of the terms of this Agreement or an
<br /> action to enforce the terms of such agreement,the prevailing party m any action shall be entiUed m recover all reasonable cost and expenses,including reasonable attomey's and legal
<br /> assistants'fees before or after any trial or litigation as well as any appellate proceedings. If any prov�sion of this Contract or the application thereof shall be invalid or unenforceable to any
<br /> extent,the remainder of this Contract is not affected thereby and shall be enforced by law '
<br /> Changes required by any and alljurisdictional code enforcement laws or ordinance may result io additional charges to the Customer and/or Owner.Convactor agrees to timely communicate
<br /> such changes and associated charges[o the Customer and/or Owner and the Customer/Owner agrees to make payment for such charges over the Contract price upon invoicing. As required by
<br /> iFlorida Statutes,Contractor has provided a�d Customer/Owner acknowledges receipt of notices concerning the Florida's Construction Lien Law,Florida Construction Industry's Recovery
<br /> Fund and[he Florida Statue Chapter 558 Notice of Claim,said notices inwrporated herein by reference.
<br /> It is the sole responsibility of the Customer and/or Owner to inform Contactor of any deed restrictions,subdivision restrictions or other matters,which may affect this Contract. It is also the
<br /> sole responsibility of the Customer and/or Owner to provide Contractor with all information needed to prepare the Notice of Commencement. The Customer and/or Owner shall hold harmless
<br /> and indemnify Convactor from all damages,liabilities,attorney's fees and other expenses incurred as a result of the Customer and/or Owner's failure to fulfill its obligatioos under this
<br /> paragraph.
<br /> Contractor reserves the right to employ and subconVact For the completion of the work described in the Co�tract. All of Contractor's workers are fully covered by WorkePs Compensa[ion
<br /> Insura�ce.
<br /> It is furthermore agreed and understood that the Contractor shall not be responsible for any damages caused by delays.It is agreed that the Contractor should be permitted to execute its work
<br /> without interruption. If.work is delayed at any time by any act or neglect of the Customer and/or Owner,or the Customer and/or Owner's representative or employees,or any o[her contractor n1
<br /> employed by the customer and/or Owner,or any changes ordered in the work,the Contractor shall be reimbursed or paid for additional expense or damage. This shall include loss of
<br /> eqmpment caused by said delay in all cases involving work stoppage,extra work,change or cancellation,it is agreed that the Customer and/or Owner will pay or reimburse the Contractor for
<br /> its full cost of iabor and materials,plus 25%overhead,plus]0%profit. Contractor shall not be held liable for any damages or delays resulting from accidents,storms,floods,eaRhquakes,war,
<br /> govemment controls,strikes,acts of God or any other accidental or natural causes,or any damage or delay beyond the Contractor's control. Contractor is not responsible for price inflation
<br /> and/or increases due to natural disasters,shortage of mater�als,increase in fueVcrude oil,hurricanes,floods,tornadoes,and/or acts of God.
<br /> ConVactor agrees to be responsible for any damages to the real property or improvements thereon of the Customer and/or Owner for other damages,directly caused by the negligence of
<br /> Contractor in the performance of their duties,except as noted herein. Contractor shall not be liable for,without limitation,damages to any vehicles in the immediate vicinity of the work in
<br /> progress,damage to driveways,sidewalks,landscaping,lawns,shrubbery,flowerbeds,gardens,pools,screen enclosures,gutters,spoutmg,window and door screens,sprinkler systems,
<br /> windows,septic systems,drain fields,garage doors,foundations or other structures,buildings,or portions thereof,as a result of work perfonned by Contractor. 1
<br /> Customer and/or Owner are responsible for satellite dish(s)/Solar Panel(s)/Lightning Rod(s)/etc.removal,installation,and re-positioning. Additionally our installation of a new roof to the
<br /> deck area of the building requires nails and/or screws to be inserted into the deck area. By code electrical,telephone and security wiring and air conditionmg wiring and lines should not be
<br /> installed direct(y beneath the roof deck. If you are aware of these or any other such lines please noti£y us immediately as the Contractor will not be responsible foc the puncture of improperly
<br /> installed lines or lines within 3 inches of the roof deck.Customer accepts full responsibility for any repair or replacement that may be necessary
<br /> Customer and/or Owner is responsible for any damage to lighting fixtures,pictures and frames,as well as these items can fall if not attached to the wall or ceiling. We suggest your check that
<br /> they are secure. If in doubt,please take them down until roofing is complete as the Co�tractor cannot accept responsibility for these items as a result of reroofing. It is also possible that small
<br /> particles of the acoustical ceiling may fall.
<br /> Contractor shall not be responsible for any injuries to Customer(s)and or Owner(s)/other employees/other companies/other contractors/subcontractors/material men.Contractor will not
<br /> be responsible for interioc damages due to any employees,inspectors,Customer and/or Owner falling through[he roof due to bad(rotted,soft,wet)wood,stucco work,old skylights,or bad
<br /> flashing. Contractor is not responsible for structural in[egrity,design or building compliance or any work done to property that has not been properly permitted,or due to poor workmanship
<br /> from builder.
<br /> The Customer shall be responsible for providi�g access for any and all trucks necessary for the delivery and/or removal of any materials and/or debris.The Customer and/or Owner agrees to
<br /> provide Contractor with access to the interior of the dwelling or building,upon reasonable notice by Contractor,to inspect for any stains,ceiling damage and/or structural damage prior to
<br /> perfotmance under the terms of[his Contract. Contractor shall not be responsible for any preexisting stains,ceiling damage and/or structural damage. ConVactor shall be held harmless by
<br /> Contractor and/or Owner for any alleged or actual damages and/or claims as a result of mold,algae or fungus. Contractor and its insurer will exclude all coverage,including defenses or
<br /> damages related to bodily injury,property damage or cleanup directly or ind'uectly for any issues associated with moid,including fungus and mildew regardless of the cost,event,material,
<br /> product or workmanship that may have contributed concurrently or in any sequence to the injury or damage occurs.
<br /> Additionally� The parties recognize and agree that the substi[utions of products and price adjustments may be required based on changes in material availability and the costs to obtain and
<br /> deliver materials the job between the daze of this proposaVcontract and when delivery is to be made to the job. In such eve nt,contractor and customer will work together in good faith to
<br /> identify substitute products that meet the customers'needs and/or the amount of the contract will be adjusted to rcflect the additional costs incurred by the contractor to obtain and have the
<br /> materials delivered to the job upon contractor's submittal of written documentation of the increased charges.
<br /> cc
<br /> This document has been prepared for those parties financially responsible for services rendered. Reliance upon this document or upon information,observations or opinions contained herein
<br /> should not be made by any party other than the intended recipient designated on the tile sheet of this estimate or report. The intent of this evaluation is to prepare an opinion of the probate
<br /> scope and/or cost of work to be performed based upon the parameters set forth by the client and the individual needs and conditions found within the s[ructure at the[ime oF inspection. This
<br /> opinion assumes a specific scope and methodology The user is cautioned that changes in either scope or methodology would have a reciprocal effect on this opinion. If this should occur,we
<br /> reserve the right to review such changes and then modify our opinion accordingly Furthermore,our opinion assumes resulting work will be competitively bid and as such it is advisable to
<br /> solicit multiple bids for such work.
<br /> Work cannot be scheduled until a full contract is signed by Customer/Owner and received in our office.
<br /> s0—�Z "� �0� �'--�� `�-+—_--' !� �—"6 2---f`-�_
<br /> Estimator—Neumann Roofing,LLC Date Customer/Owner Date
<br /> For Internal Use Only: Job Name: Job Number PAGE 3 OF 5
<br />
|