|
GENERAL NOTES
<br />EXISTING CONDITIONS SHOWN ON THESE CONTRACT
<br />DOCUMENTS ARE BASED ON AVAILABLE INFORMATION.
<br />PRIOR TO CONSTRUCTION, FEILD VERIFY ALL EXISTING
<br />CONDITIONS AND NOTIFY THE ARCHITECT IF ANY
<br />INFORMATION FOUND ON THE CONTRACT DOCUMENTS
<br />CONFLICTS WITH THE FIELD VERIFIED CONDITIONS.
<br />IF ANY EXISTING CONDITIONS CONFLICT WITH CODE OF
<br />SAFETY REQUIREMENTS, NOTIFY THE ARCHITECT
<br />IMMEDIATELY.
<br />COMPLETE CONSTRUCTION DOCUMENTS ARE TO BE
<br />MAINTAINED ON THE PROJECT SITE AT ALL TIMES. THESE
<br />CONSTRUCTION DOCUMENTS SHALL HAVE CURRENT
<br />ADDENDA, ARCHITECT'S SUPPLEMENTAL INSTRUCTIONS,
<br />SUPPLEMENTAL DRAWINGS, ANY APPLICABLE NOTES,
<br />ETC.
<br />DIMENSIONS GOVERN, DO NOT SCALE DRAWINGS.
<br />"TYP " MEANS THE REFERENCE DETAIL SHALL APPLY FOR
<br />ALL SIMILAR CONDITIONS UNLESS OTHERWISE NOTED.
<br />PROVIDE FIRE -RETARDANT TREATED WOOD FOR ALL
<br />WOOD BLOCKING AND NAILERS USED IN CONCEALED
<br />SPACES.
<br />THE ARCHITECT DOES NOT HAVE CONSTRUCTION
<br />ADMINISTRATION FOR THIS PROJECT NOR DOES THE
<br />ARCHITECT HAVE ANY CONTRACTUAL OBLIGATION TO THE
<br />CLIENT BEYOND THE PREPARATION OF PERMITABLE
<br />DOCUMENTS.
<br />ALL CONTRACTORS, SUB -CONTRACTORS AND
<br />CONSULTANTS SHALL BE RESPONSIBLE FOR
<br />PROFESSIONAL AND PROPER PERFORMANCE OF THEIR
<br />WORK, COORDINATION, MEANS AND METHODS, SAFETY
<br />AND SECURITY AT THE JOB SITE.
<br />CONTRACTOR SHALL VERIFY EXISTING POWER IS
<br />ADEQUATE FOR TENANT REQUIREMENTS.
<br />INSTALL 75 CFM EXHAUST FAN IN ALL TOILET ROOMS,
<br />UNO.
<br />GENERAL CONTRACTOR SHALL PROVIDE ALL TEMPORARY
<br />CONSTRUCTION BARRICADES AS REQUIRED.
<br />ALL DEMOLITION WORK SHALL COMPLY WITH O.S.H.A.
<br />STANDARDS.
<br />GENERAL CONTRACTOR SHALL BE RESPONSIBLE FOR
<br />PROVIDING PROPER SHORING AND BRACING AS
<br />REQUIRED TO SAFELY EXECUTE ALL WORK.
<br />REMOVE ALL DEBRIS AND DISCARD PROPERLY. ANY
<br />REMAINING MATERIALS ARE TO BE MADE AWARE TO THE
<br />OWNER BEFORE REMOVAL FROM SITE.
<br />PATCH AND REPAIR ALL SURFACES, AREAS AND ITEMS
<br />REMAINING WHICH ARE DAMAGED OR HAVE BEEN
<br />DAMAGED DUE TO MODIFICATIONS.
<br />LIMITATION OF DRAWINGS
<br />THESE DRAWINGS DELINEATE THE SCOPE OF THIS PROJECT AND
<br />ESTABLISH THE PERFORMANCE STANDARD, WHICH SHALL BE
<br />REQUIRED BY THE GENERAL CONTRACTOR.
<br />PRIOR TO SUBMITTING BIDS, THE GENERAL CONTRACTOR SHALL VISIT
<br />THE SITE TO BECOME FAMILIAR WITH ALL EXISTING CONDITIONS,
<br />EXISTING FACILITIES AND ALL BUILDING STRUCTURES, EXTENT OF
<br />WORK TO BE DONE AND ANY OTHER CONDITIONS WHICH MAY AFFECT
<br />WORK TO BE DONE, EQUIPMENT (IF APPROPRIATE), MATERIALS AND
<br />LABOR REQUIREMENTS UNDER SUPERVISION BY THE CONTRACTOR OF
<br />RECORD.
<br />IN THE CONTEXT OF INSTALLATION AND OTHER CONSTRUCTION
<br />ASPECTS WHERE THESE DRAWINGS MAY NOT BE COMPLETE.THE
<br />GENERAL CONTRACTOR MUST SUPPLEMENT THE DRAWINGS WITH
<br />FIELD INVESTIGATION NOTES PRIOR TO SUBMITTAL OF BIDS.
<br />THE GENERAL CONTRACTOR SHALL ANTICIPATE VARIATIONS OF
<br />ROUTINES AND CONSTRUCTION, TO AVOID CONFLICT WITH OTHER
<br />TRADES. THIS EXTRA WORK SHALL BE INCLUDED AS PART OF THE
<br />REQUIRED WORK AT NO ADDITIONAL COST TO THE OWNER. ALL WORK
<br />AND/OR MATERIALS REQUIRED TO COMPLETE THE SCOPE OF THIS
<br />PROJECT SHALL IN NO WAY CAUSE FOR ADDITIONAL COMPENSATION.
<br />GENERAL CONDITIONS
<br />PAYMENT TERMS:
<br />PAYMENT IS SOLELY BASED UPON PERCENT COMPLETE AS
<br />DEFINED ABOVE OR JMA, INC. CHARGES INCURRED OF EACH
<br />TASK AND NOT THE ACQUISITION OF ANY JURISDICTION
<br />APPROVALS OR PERMITS.
<br />ARCHITECT AND THE CONSULTANT MEMBERS HAVE THE RIGHT
<br />TO STOP ALL WORK AND WILL EXERCISE THAT RIGHT AT ANY
<br />TIME IT DEEMS NECESSARY TO OBTAIN PAYMENT FOR
<br />OUTSTANDING INVOICES. THE CLIENT WILL HOLD THE
<br />ARCHITECT AND CONSULTANT MEMBERS HARMLESS FOR ANY
<br />REPERCUSSIONS DUE TO A STOP -WORK DIRECTIVE RESULTING
<br />FROM A LACK OF PAYMENT.
<br />PAYMENT FOR WORK COMPLETED WILL BE DUE FROM THE
<br />OWNER AT THE TIME THE DELIVERABLES ARE SUBMITTED FOR
<br />APPROVAL BY THE OWNER REGARDLESS OF WHETHER THE
<br />OWNER ELECTS TO PROCEED WITH THE PROJECT OR NOT.
<br />OWNER'S RESPONSIBILITY:
<br />THE OWNER SHALL FURNISH SURVEYS DESCRIBING PHYSICAL
<br />CHARACTERISTICS, LEGAL LIMITATIONS AND UTILITY
<br />LOCATIONS FOR THE SITE OF THE PROJECT, AND A WRITTEN
<br />LEGAL DESCRIPTION OF THE SITE. THE SURVEYS AND
<br />LEGAL INFORMATION SHALL INCLUDE, AS APPLICABLE, GRADES
<br />AND LINES OF STREETS, ALLEYS PAVEMENTS AND
<br />ADJOINING PROPERTY AND STRUCTURES; ADJACENT DRAINAGE;
<br />RIGHTS -OF -WAY, RESTRICTIONS, EASEMENTS,
<br />ENCROACHMENTS, ZONING, DEED RESTRICTIONS, BOUNDARIES
<br />AND CONTOURS OF THE SITE; LOCATIONS,
<br />DIMENSIONS AND NECESSARY DATA PERTAINING TO EXISTING
<br />BUILDINGS, OTHER IMPROVEMENTS AND TREES;
<br />AND INFORMATION CONCERNING AVAILABLE UTILITY SERVICES
<br />AND LINES, BOTH PUBLIC AND PRIVATE, ABOVE
<br />AND BELOW GRADE, INCLUDING INVERTS AND DEPTHS. ALL THE
<br />INFORMATION ON THE SURVEY SHALL BE
<br />REFERENCED TO A PROJECT BENCHMARK.
<br />THE ARCHITECT SHALL NOT BE REQUIRED TO FURNISH ANY
<br />SERVICE IN ADDITION TO THE PRODUCTION OF THE
<br />INSTRUMENTS OF SERVICE OR BE REQUIRED TO RETAIN ITS OWN
<br />CONSULTANTS UNLESS SPECIFICALLY AGREED TO HEREIN.
<br />ANY AND ALL CONSULTANTS RETAINED FOR THE PURPOSES OF THE
<br />PROJECT SHALL ENTER INTO DIRECT
<br />CONTRACTUAL OBLIGATION WITH OWNER AND SHALL NOT BE
<br />CONSIDERED FOR ANY PURPOSE TO HAVE ANY
<br />CONTRACTUAL RELATIONSHIP WITH THE ARCHITECT. THE
<br />ARCHITECT WILL COORDINATE AND MANAGE ALL
<br />REQUIRED CONSULTANTS FOR COMPLETION OF PROJECT.
<br />THE OWNER SHALL FURNISH THE SERVICES OF ADDITIONAL
<br />CONSULTANTS INCLUDING BUT NOT LIMITED TO
<br />THE SERVICES OF AN ENGINEER WHOM SHALL ACT WITH FINAL
<br />AUTHORITY TO AUTHENTICATE AND/OR CERTIFY THE
<br />ADDITIONAL SERVICES OF THE CONSULTANTS.
<br />REMODELING, REHABILITATION, RENOVATION OR
<br />RESTORATION
<br />THE ARCHITECTS SERVICES SHALL BE PROVIDED TO ASSIST THE
<br />OWNER IN MAKING CHANGES TO AN EXISTING FACILITY FOR
<br />WHICH THE OWNER SHALL FURNISH DOCUMENTATION AND
<br />INFORMATION UPON WHICH THE ARCHITECT MAY RELY FOR ITS
<br />ACCURACY AND COMPLETENESS. THE ARCHITECT SHALL NOT BE
<br />REQUIRED TO PERFORM OR TO HAVE OTHERS PERFORM
<br />DESTRUCTIVE TESTING OR TO INVESTIGATE CONCEALED OR
<br />UNKNOWN CONDITIONS. IN THE EVENT DOCUMENTATION OR
<br />INFORMATION FURNISHED BY THE OWNER IS INACCURATE OR
<br />INCOMPLETE, ALL RESULTING DAMAGES, LOSSES AND
<br />EXPENSES, INCLUDING THE ARCHITECT'S ADDITIONAL SERVICES,
<br />SHALL BE BORNE BY THE OWNER.
<br />THE OWNER SHALL INDEMNIFY AND HOLD HARMLESS THE
<br />ARCHITECT, THE ARCHITECT'S CONSULTANTS, AND AGENTS AND
<br />EMPLOYEES OF ANY OF THEM FROM AND AGAINST CLAIMS,
<br />DAMAGES, LOSSES AND EXPENSES, INCLUDING BUT NOT
<br />LIMITED TO ATTORNEYS FEES, WHICH ARISE AS A RESULT OF
<br />DOCUMENTATION INFORMATION FURNISHED BY THE OWNER.
<br />THE OWNER SHALL PROVIDE PROMPT WRITTEN NOTICE TO THE
<br />ARCHITECT IF THE OWNER BECOMES AWARE OF
<br />ANY FAULT OR DEFECT IN THE PROJECT, INCLUDING ANY
<br />ERRORS, OMISSIONS OR INCONSISTENCIES IN THE
<br />ARCHITECT'S INSTRUMENTS OF SERVICE.
<br />GENERAL CONDITIONS
<br />INSTRUMENTS OF SERVICE:
<br />DRAWINGS, SPECIFICATIONS, AND OTHER DOCUMENTS,
<br />INCLUDING THOSE IN ELECTRONIC FORM, PREPARED BY
<br />THE ARCHITECT ARE INSTRUMENTS OF SERVICE FOR USE
<br />SOLELY WITH RESPECT TO THIS PROJECT. THE ARCHITECT
<br />SHALL BE DEEMED THE AUTHORS AND OWNERS OF THEIR
<br />RESPECTIVE INSTRUMENTS OF SERVICE AND SHALL RETAIN
<br />ALL COMMON LAW, STATUTORY AND OTHER RESERVED RIGHTS,
<br />INCLUDING COPYRIGHTS.
<br />UPON EXECUTION OF THIS AGREEMENT, THE ARCHITECT GRANTS
<br />TO THE OWNER A NONEXCLUSIVE LICENSE TO
<br />REPRODUCE THE DESIGNER'S INSTRUMENTS OF SERVICE
<br />SOLELY FOR PURPOSES OF CONSTRUCTING, USING AND
<br />MAINTAINING THE PROJECT, PROVIDED THAT THE OWNER SHALL
<br />COMPLY WITH ALL OBLIGATIONS, INCLUDING
<br />PROMPT PAYMENT OF ALL SUMS WHEN DUE, UNDER THIS
<br />AGREEMENT. ANY TERMINATION OF THIS
<br />AGREEMENT PRIOR TO COMPLETION OF THE PROJECT SHALL
<br />TERMINATE THIS LICENSE. UPON SUCH TERMINATION,
<br />THE OWNER SHALL REFRAIN FROM MAKING FURTHER
<br />REPRODUCTIONS OF INSTRUMENTS OF SERVICE AND SHALL
<br />RETURN TO THE ARCHITECT WITHIN SEVEN DAYS OF
<br />TERMINATION ALL ORIGINALS AND REPRODUCTIONS IN THE
<br />OWNER'S POSSESSION OR CONTROL. IF AND UPON THE DATE
<br />THE ARCHITECT IS ADJUDGED IN DEFAULT OF THIS AGREEMENT,
<br />THE FOREGOING LICENSE SHALL BE DEEMED TERMINATED AND
<br />REPLACED BY A SECOND, NONEXCLUSIVE
<br />LICENSE PERMITTING THE OWNER TO AUTHORIZE OTHER
<br />SIMILARLY CREDENTIALED OR ADDITIONS TO THE
<br />INSTRUMENTS OF SERVICE SOLELY FOR PURPOSES OF
<br />COMPLETING, USING AND MAINTAINING THE PROJECT.
<br />THE OWNER SHALL NOT USE THE INSTRUMENTS OF SERVICE FOR
<br />FUTURE ADDITIONS OR ALTERATIONS TO THIS PROJECT OR FOR
<br />OTHER PROJECTS, UNLESS THE OWNER OBTAINS THE PRIOR
<br />WRITTEN AGREEMENT OF THE ARCHITECT. ANY UNAUTHORIZED
<br />USE OF THE INSTRUMENTS OF SERVICE SHALL BE AT THE
<br />OWNER'S SOLE RISK AND WITHOUT LIABILITY TO THE ARCHITECT.
<br />ADDITIONAL SERVICES:
<br />ANY ADDITIONAL WORK OUTSIDE THE SCOPE OF THIS
<br />AGREEMENT WILL BE CHARGED AT AN HOURLY RATE:
<br />$95.00/HR.
<br />REIMBURSABLE EXPENSES:
<br />COSTS RELATED TO THE PROJECT:
<br />ADDITIONAL PRINTS AND COPIES OF DRAWINGS/ DOCUMENTS
<br />BEYOND PRESENTATION SET OF 2 COPIES.
<br />HANDLING OF PROJECT DOCUMENT (SUCH AS FEDEX, EXPRESS
<br />MAIL, OR MESSENGER SERVICES)
<br />PRESENTATION BOARDS AND MOUNTING
<br />TRAVEL RELATED COSTS OUTSIDE OF DELIVERABLE
<br />SUBMISSIONS.
<br />PROFESSIONAL LIABILITY:
<br />THE PARTIES AGREE THAT ALL DISPUTES BETWEEN THEM WILL
<br />BE SUBMITTED TO A MUTUALLY AGREEABLE NEUTRAL
<br />MEDIATOR, AS A CONDITION PRECEDENT TO LITIGATION OR
<br />OTHER REMEDIES PROVIDED BY LAW. THE FEE AND COSTS OF
<br />THE MEDIATOR SHALL BE APPORTIONED EQUALLY BETWEEN THE
<br />PARTIES.
<br />THE ARCHITECT AND CONSULTANT MEMBERS SHALL NOT BE
<br />RESPONSIBLE FOR DELAYS CAUSED BY FACTORS BEYOND ITS
<br />REASONABLE CONTROL, INCLUDING BUT NOT LIMITED TO
<br />DELAYS CAUSED BY ACTS OF GOD, ACCIDENTS, FAILURE OF ANY
<br />GOVERNMENTAL OR OTHER REGULATORY AUTHORITY TO ACT IN
<br />A TIMELY MANNER, OR FAILURE OF CLIENT TO FURNISH TIMELY
<br />INFORMATION OR TO APPROVE OR DISAPPROVE THE WORK
<br />PRODUCTS PROMPTLY.
<br />NEITHER PARTY WILL BE LIABLE TO THE OTHER FOR SPECIAL,
<br />INCIDENTAL, CONSEQUENTIAL OR PUNITIVE LOSSES OR
<br />DAMAGES, INCLUDING BUT NOT LIMITED TO DAMAGES
<br />RESULTING FROM DELAY, LOSS OF USE, LOSS OF PROFITS OR
<br />REVENUE,
<br />OR COST OF CAPITAL ASSOCIATED WITH THIS PROJECT.
<br />NEITHER PARTY WILL BE LIABLE TO THE OTHER UNLESS SUIT IS
<br />COMMENCED WITHIN TWO YEARS OF THE DATE OF LOSS OR
<br />INJURY, OR WITHIN TWO YEARS AFTER THE COMPLETION OF
<br />SERVICES, WHICHEVER IS EARLIER. THE ARCHITECT SHALL
<br />PERFORM SERVICES AS OUTLINED IN A PROFESSIONAL MANNER.
<br />LIMITED LIABILITY WILL BE APPLIED TOWARDS THIS PROJECT UP
<br />TO ONE-THIRD THE FINAL AMOUNT AGREED FEE FOR SERVICES IF
<br />AFTER JUDGEMENT IN A COURT OF LAW FINDS THE DESIGN
<br />TEAM LIABLE AND THE OWNER AGREES TO HOLD HARMLESS,
<br />INDEMNIFY, AND DEFEND THE ARCHITECT FROM ALL CLAIMS,
<br />LOSSES AND EXPENSES, INCLUDING ATTORNEY FEES. THE
<br />ARCHITECT WILL NOT BE LIABLE FOR COST OF REPAIRS FROM
<br />ERRORS AND OMISSIONS NOR DELAY IN CONSTRUCTION FOR
<br />THIS PROJECT.
<br />PURSUANT TO SECTION 558.0035,
<br />FLORIDA STATUTES, THE PARTIES
<br />UNDERSTAND AND AGREE THAT
<br />ARCHITECT'S EMPLOYEES OR
<br />AGENTS MAY NOT BE SUED OR
<br />HELD INDIVIDUALLY LIABLE FOR
<br />NEGLIGENT PERFORMANCE OF THIS
<br />AGREEMENT.
<br />GENERAL CONDITIONS
<br />THE ARCHITECT AND CONSULTANT MEMBERS SHALL NOT HAVE
<br />AUTHORITY OVER THE CONTRACTOR'S WORK OR RESPONSIBILITY FOR
<br />METHODS OR PROCEDURES OF CONSTRUCTION SELECTED BY THE
<br />CONTRACTOR, OR FOR SAFETY PRECAUTIONS INCIDENT TO THE
<br />WORK OF THE CONTRACTOR, OR FOR ANY FAILURE OF THE
<br />CONTRACTOR TO COMPLY WITH THE CLIENT'S AND/OR
<br />JURISDICTIONSRULES, REGULATIONS, ORDINANCES, OR CODES
<br />APPLICABLE TO THE CONTRACTOR FURNISHING AND PERFORMING
<br />THE WORK.
<br />THE PARTIES FURTHER AGREE THAT THE STANDARD OF CARE
<br />FOR THE PERFORMANCE UNDER THIS AGREEMENT SHALL BE
<br />THAT DUTY AND CARE ASSOCIATED WITH THIS TYPE OF WORK IN
<br />THE LOCAL JURISDICTION AND THAT THE PROPER VENUE FOR
<br />LITIGATION OF ANY CAUSE OF ACTION HERETO SHALL BE THAT
<br />LOCAL COURT OF JURISDICTION OF THE PROJECTS LOCATION.
<br />THE SCOPE OF THE ARCHITECT AND CONSULTANT
<br />MEMBERS SERVICE HEREUNDER IS STRICTLY LIMITED TO
<br />THE SERVICES DESCRIBED IN THE SCOPE OF SERVICES,
<br />AND WE SHALL HAVE NO OBLIGATIONS BEYOND SUCH
<br />SCOPE. FURTHER, THE ARCHITECT AND CONSULTANT MEMBERS
<br />SHALL HAVE NO OBLIGATION TO PERFORM, AND SHALL NOT BE
<br />LIABLE FOR ANY INVESTIGATIONS OR INSPECTION RELATING TO
<br />THE PROJECT, UNLESS SUCH INVESTIGATIONS OR INSPECTIONS
<br />ARE EXPRESSLY PROVIDED IN THIS CONTRACT. THE CLIENT
<br />SHALL PAY THE ARCHITECT AND CONSULTANT MEMBERS
<br />ADDITIONAL FEES AND REIMBURSABLE FOR WORK REQUIRED
<br />FOR THE PROJECT OR FOR SERVICES REQUESTED BY CLIENT,
<br />ORAL OR WRITTEN, IF SUCH WORK OR SERVICES ARE NOT
<br />EXPRESSLY DESCRIBED IN THE CONTRACT, INCLUDING, BUT NOT
<br />LIMITED TO, SERVICES INVOLVING REDESIGN, CHANGE IN SCOPE
<br />OF THE PROJECT OR ADDITIONAL WORK OR SERVICES
<br />RESULTING FROM DELAYS CAUSED BY OTHER THAN THE
<br />ARCHITECT AND CONSULTANT MEMBERS.
<br />CONSTRUCTION PHASE SERVICES (IF REQUESTED):
<br />THIS PROPOSAL DOES NOT INCLUDE ANY CONSTRUCTION
<br />ADMINISTRATION, SITE VISITS, VALUE ENGINEERING, COST
<br />REDUCTION DRAWING REVISIONS, GEO-TECH ANALYSIS,
<br />PLACEMENT OF SEPTIC TANK AND SEPTIC PERMIT, OR
<br />ENVIRONMENTAL ENGINEERING. THESE MAY BE COMPLETED AS
<br />AN ADDITIONAL SERVICE.
<br />SCHEDULE OF CHARGES:
<br />PRINCIPAL RATE = $125.00
<br />PROJECT MANAGER RATE = $95.00
<br />PROJECT COORDINATE RATE = $75.00
<br />DRAFTSMAN RATE = $65.00
<br />CONSULTANT MEMBER RATE = AS PER THEIR OWN TERMS AND
<br />CONDITIONS AS REQUIRED
<br />OWNERS AGREED SIGNATURE:
<br />BY ACCEPTANCE OF THIS SET OF DOCUMENTS WITHIN, THE
<br />OWNER IS AGREEING TO THE TERMS AND CONDITIONS OF THIS
<br />AGREEMENT. PAYMENT FOR SERVICES WILL BE DUE UPON
<br />SUBMISSION OF DELIVERABLES NOTED ABOVE. ALL ADDITIONAL
<br />SERVICES REQUESTED BY THE OWNER SHALL BE APPROVED IN
<br />WRITING PRIOR TO IMPLEMENTING THESE SERVICES.
<br />SHOP DRAWINGS
<br />THERE SHALL NOT BE ANY DEVIATIONS FROM THESE DESIGN PLANS
<br />BY OTHERS DURING THE PREPARATION OF SHOP DRAWINGS WITHOUT
<br />WRITTEN APPROVAL FROM THE ENGINEER OF RECORD.
<br />ALL SHOP DRAWINGS ARE TO BE SUBMITTED TO THE ENGINEER OF
<br />RECORD PRIOR TO THE COMMENCEMENT OF CONSTRUCTION.
<br />ALL ITEMS IDENTIFIED OR INTENDED TO BE DESIGNED BY OTHERS REQUIRE
<br />SHOP DRAWINGS TO BE SIGNED AND SEALED AND SHALL INCLUDE;
<br />DRAWINGS AND CALCULATIONS, REACTIONS AND BEARING POINTS,
<br />BRACING REQUIREMENTS, LIFTING LOCATIONS, AND CONNECTIONS
<br />TO SUPPORTING TRUSS MEMBERS.
<br />V In
<br />z 1,.-
<br />_ r" L
<br />0)
<br />Lu r-1 't
<br />Z) �_ TT
<br />0
<br />■
<br />F—�M
<br />Q
<br />U
<br />z
<br />� uj
<br />00
<br />u zT
<br />� u.l
<br />Q > L
<br />+�
<br />N
<br />..z=wo
<br />ro
<br />Q I� J Mo
<br />U
<br />to
<br />UV) U- NO
<br />Q o
<br />a)Q
<br />(�
<br />W
<br />w N N
<br />C
<br />Q
<br />N
<br />><
<br />W
<br />d-
<br />Lo
<br />oco
<br />M
<br />U
<br />LL
<br />W
<br />Z
<br />�
<br />o
<br />O
<br />U r
<br />=
<br />W
<br />M
<br />WM�
<br />0
<br />Lo
<br />N
<br />ISSUE RECORD
<br />REVISION NO./DATE:
<br />DESCRIPTION:
<br />GENERAL CONDITIONS
<br />JOB No.: 19-023
<br />DWN BY: MA
<br />CHK BY: JLM
<br />DATE ISSUED: 05.07.19
<br />SHEET NO:
<br />GC
<br />
|